Lane Closures Sample Clauses

Lane Closures. Where construction of the Project shall involve lane closures public streets, the following shall apply: • Lane closures require a Lane Closure Permit, obtained two weeks prior to planned construction, with a minimum 48-hour prior notice to local police and emergency departments (some police jurisdictions may require considerably more notice). Lane closures of a one day or less duration will generally not be approved for major collector streets or for arterial streets during the hours of 7am to 9am and 4pm to 6pm weekdays.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Lane Closures. Approval for all lane closures, mobile operations, and traffic pacing operations is required. Submit routine requests to the Engineer fourteen calendar days in advance of planned lane closures, mobile operations, and traffic pacing operations. For unforeseen events that require cancelling or rescheduling lane closures, mobile operations, and traffic pacing operations, revise the lane closure request as soon as possible.
Sample 1Sample 2
Lane Closures. 15.3.1 Lane Closures during construction of the Works will be dealt with in accordance with Section 11.8 [Traffic Management During Construction].
Sample 1Sample 2
Lane Closures. Failure to reopen lanes at the times specified in Section 150.6 will result in liquidated damages at a rate of $1000.00 per hour or any part thereof. These rates are in addition to Liquidated Damages that may be assessed in accordance with Subsection 108.08 for failure to complete the overall project. Office of Maintenance
Sample 1
Lane Closures. Any planned closure on NTTA roadways, including travel lanes and shoulders, or other activities that might impact the traffic flow and safety of the traveling public, must be reported in advance to the NTTA Lane Closure Management Team for review and approval. All closure requests must be submitted using the XxxxXxxx Xxxx Closure Application (LCA) if the NTTA network login has been granted. For those without NTTA network access, the closure requests should be submitted using the NTTA Lane Closure Website (LCW) at xxx.xxxxxx.xxx. Accounts for both LCA and LCW will be granted with a request to the Lane Closure Management Team at xxxxxxxxxxx@xxxx.xxx. The NTTA Lane Closure Request Form can be used when either account is not available or for closures that are outside of NTTA jurisdiction and require approval by other agencies. The Lane Closure Request Form can be obtained from the NTTA website or the Engineer. All lane closure requests must meet the advance notification requirements as specified below:
Sample 1
Lane Closures. Failure to reopen lanes at the times specified in Section 150.11 will result in liquidated Damages at a rate of $1,000.00 per Hour or any part thereof. PLEASE NOTE: THESE RATES ARE IN ADDIONTION TO LIQUIDITAED DAMAGES THAT MAY BE ASSESSED IN ACCORDANCE WITH SUB-SECTION 108.08 FOR FAILURE TO COMPLETE THE OVERALL PROJECT. Schedule of Deductions for Each Day of Overrun in Contract Time Original Contract Amount Daily Charges From More Than To and Including Available Day Calendar Day or Completion Date $0 $500,000 $118 $84 $500,000 $1,000,000 $211 $151 $1,000,000 $2,000,000 $346 $247 $2,000,000 $5,000,000 $547 $391 $5,000,000 $10,000,000 $998 $713 $10,000,000 $20,000,000 $1,667 $1,191 $20,000,000 $40,000,000 $2,617 $1,869 $40,000,000 ----------- $7,125 $5,089 When the Contract Time is on either the calendar day or completion date basis, the schedule for calendar days shall be used. When the Contract Time is based on an available day basis, the schedule for available days shall be used. For each Calendar Day or Available Day, as specified, that any work shall remain uncompleted after the contract time specified for the completion of The Work required by the Contract, the sum specified in the Contract will be deducted from any money due the Contractor, not as a penalty, but as liquidated damages; provided however, that due account shall be taken of any adjustment of the contract time for completion of the work granted under the provisions of Subsection 108.07.E. The Department may waive such portions of the liquidated damages as may accrue after the work is in condition for safe and convenient use by the traveling public.
Sample 1
Lane Closures. KUB will need notice a week ahead of time to process notifications for Lane Closures. • ARAP General Conditions & Crossing Descriptions included in this Addendum.
Sample 1
AutoNDA by SimpleDocs
Lane Closures. The Contractor shall be responsible for lane closures or narrow a lane of traffic, detain and/or alter the traffic flow, as needed, to complete the required work. Traffic plan shall be reported to Facilities Director, as needed. Parking Lot A Construction: • It is the intention of this bid to cover the preparation and construction of Parking Lot A to confirm to all City of Xxxxxxx, Xxxxxxx County, and Texas Department of Transportation specifications. It will be the responsibility of the Contractor to perform all required elements to suitably prepare the subsurface prior to installation of the parking area base. • Parking Lot A shall be prepared and constructed with base rock material to be finished out with asphalt at a later date. This lot will serve as a construction staging site for an upcoming project. Base preparation and materials shall be constructed to maintain heavy equipment and vehicle traffic. • Temporary curbs and guttering shall be within the required guidelines of the City of Xxxxxxx for this temporary site. Parking Lot B Construction: • It is the intention of this bid to cover the preparation and construction of Parking Lot B to confirm to all City of Xxxxxxx, Xxxxxxx County, and Texas Department of Transportation specifications. Parking Lot B shall serve as employee parking for Grayson County. • Parking lot pavement shall be six (6) inches of flex base and 2 inches of asphalt. • Approaches to be built to meet the City of Xxxxxxx’x specifications. • This parking lots shall have two (2) entrances. This is a utility pole and communications boxes that these entrances will split. Proper care shall be taken not to disturb these utilities. Utility locating will be at the responsibility of the Contractor. • Proper curb and guttering shall be required according to measurements listed below. • Sidewalk shall be constructed utilizing per the City of Xxxxxxx’x specifications. • Parking spot striping shall be according to the photo provided in Exhibit X. Xxxxxxx County anticipates lot providing 54 parking stalls. • Two (2) Approaches/Entrances to the lot entering/exiting from Xxxxxxxx St. There are utilities located in between where the two approaches should be places. Surveys – Contractor will furnish all stakes and furnish inspector with suitable assistance for making any required surveys in connections with location structures and final measurements of quantities of items installed. Contact Xxxxx Xxxxx, Facilities Director at 000-000-0000 for lot s...
Sample 1
Lane Closures 
Sample 1

Related to Lane Closures

  • School Closures If school must be canceled, the school year shall be extended and vacations and in-service days and holidays not required by Statute may be utilized to meet State and District curriculum requirements. The district will consult with the President of the Association (s) before revising the calendar as required. Such time will be made up without additional pay. Any student school days waived by OSPI due to emergency school closure shall also be work days waived for certificated staff. There shall be no loss of pay in such an instance.

  • School Closure The School shall make reasonable efforts to promptly notify the public, which may include notice to the Department of Education, of any circumstance requiring the closure of the School, including, but not limited to, a natural disaster, such as an earthquake, storm, tsunami, flood, or other weather-related event, other extraordinary emergency, or destruction of or damage to the School facility;

  • PLANT CLOSURE 29.01 In the event the Company closes the plant at the Cambridge location as a result of the loss of business or a discontinuation of all operations, severance pay will be calculated at one (1) week’s regular pay per year of service. The severance payment, so calculated, is inclusive of any severance payment required by the Ontario Employment Standards Act (Revised 2000). This agreement is not applicable to a sale of the business or if the closure is occasioned by a labour dispute.

  • Christmas Closedown 15.1 It is agreed that whenever annual leave is taken in conjunction with the Christmas/New Year period (as per Calendar in sub-clause 2.11), it is to be taken in accordance with the following procedure.

  • Closures PROVIDER agrees compensation for temporary closures will be handled in accordance with Office of Early Learning Rule 6M-8.204(5), F.A.C.

  • Emergency Closures A. The University’s inability to make a Room available to me for any reason beyond the University’s control including, but not limited to, natural disaster, fire, flood, earthquake, condemnation, pandemic, quarantine, utility malfunction, infestation, or other emergency or force majeure event shall not constitute a breach of this Agreement by the University. In such circumstances, the University shall have no liability to me in any way for injuries, reimbursement, damages, inconvenience, annoyance or compensation of any kind. The University may attempt to find, but cannot guarantee, an alternative space for me. If the unavailability of my Room or an alternative space persists for more than 72 hours, I may terminate this Agreement and Check out during said unavailability without penalty provided that I shall be responsible for all financial obligations incurred up to the date of such termination. The University agrees to provide me with a pro rata refund, calculated from the date of such termination to the end of the Agreement Period, of any prepaid housing and dining payment made to the University, and to return my Deposit pursuant to this Agreement. Upon resumption of standard operations, Agreement Termination requirements and charges will apply as described in Section XIV.

  • School Closings In the event of any school closing, employees will report for duty only if so requested by an appropriate supervisor. Employees requested to report for duty will be compensated by receiving an alternative day off agreed upon with their supervisor. Employees not requested to report would be paid for up to five (5) days of school closing or such days will be made up if all other employees are required to make up such days.

  • Closings On each Advance Date, which shall be seven (7) Trading Days after an Advance Notice Date, (i) the Company shall deliver to the Investor's Counsel, as defined pursuant to the Escrow Agreement, shares of the Company's Common Stock, representing the amount of the Advance by the Investor pursuant to Section 2.1 herein, registered in the name of the Investor which shall be delivered to the Investor, or otherwise in accordance with the Escrow Agreement and (ii) the Investor shall deliver to First Union National Bank (the "ESCROW AGENT") the amount of the Advance specified in the Advance Notice by wire transfer of immediately available funds which shall be delivered to the Company, or otherwise in accordance with the Escrow Agreement. In addition, on or prior to the Advance Date, each of the Company and the Investor shall deliver to the other through the Investor's Counsel all documents, instruments and writings required to be delivered or reasonably requested by either of them pursuant to this Agreement in order to implement and effect the transactions contemplated herein. Payment of funds to the Company and delivery of the Company's Common Stock to the Investor shall occur in accordance with the conditions set forth above and those contained in the Escrow Agreement; PROVIDED, HOWEVER, that to the extent the Company has not paid the fees, expenses, and disbursements of the Investor or its Investor's counsel in accordance with Section 12.4, the amount of such fees, expenses, and disbursements may be deducted by the Investor (and shall be paid to the relevant party) from the amount of the Advance with no reduction in the amount of shares of the Company's Common Stock to be delivered on such Advance Date.

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • School Closing In the event that school is closed for any reason and the School District does not require employees to perform services, employees shall be compensated as follows:

Time is Money Join Law Insider Premium to draft better contracts faster.