Lane Closure definition
Lane Closure means closure of any traffic lane, or the reduction in width of any traffic lane to
Lane Closure means full or partial closure of any travel lane or shoulder in any portion of the Project and for any duration, including main lanes, ramps, direct connectors, frontage roads and cross streets.
Lane Closure means a circumstance where the minimum width of Lane required in accordance with Chapter 8 of the Traffic Signs Manual to permit passage by all classes of vehicle is not available.
Examples of Lane Closure in a sentence
Consequently, Maintenance Contractor agrees to pay TxDOT the following sums of money (“Liquidated Damages for Lane Closures”) as deemed compensation to TxDOT resulting from Maintenance Contractor’s failure to meet the Lane Closure restrictions herein.
More Definitions of Lane Closure
Lane Closure means a closure of an individual lane or lanes for the purposes of work while maintaining traffic flow in the direction of travel.
Lane Closure means closure of any traffic lane, or the reduction in width of any traffic lane to less than the widths specified in Section 26.2.1.2 of the Design-Build Specifications, in any portion of the Project or a connecting highway, as applicable, and for any duration, including main lanes, ramps, direct connectors, frontage roads, access roads and cross roads. Liquidated Damages means the liquidated damages, including Liquidated Damages for Delay, Key Personnel Unavailability Liquidated Damages and Liquidated Damages for Lane Closures, specified in DBA Sections 7.2, 7.3 and 7.4, and General Conditions Sections 8.3.1, 8.7.1.1 and 8.7.2.1.
Lane Closure means the reduction of a travel lane width to less than the minimum allowed or closure of a travel lane to bus or vehicular traffic, as a result of Construction of the Infrastructure, including activities within a road segment.
Lane Closure means full or partial closure of any traffic lane in any portion of the Project or a connecting highway, as applicable, and for any duration, including main lanes, ramps, direct connectors, frontage roads and cross roads. Law or Laws means (a) any statute, law, code, regulation, ordinance, rule or common law, (b) any binding judgment (other than regarding a Claim or Dispute), (c) any binding judicial or administrative order or decree (other than regarding a Claim or Dispute), (d) any written directive, guideline, policy requirement or other governmental restriction (including those resulting from the initiative or referendum process, but excluding those by TxDOT within the scope of its administration of the Contract Documents) or (e) any similar form of decision of or determination by, or any written interpretation or administration of any of the foregoing by, any Governmental Entity, in each case which is applicable to or has an impact on the Project or the Work, whether taking effect before or after the Effective Date, including Environmental Laws. “Laws”, however, excludes Governmental Approvals.
Lane Closure means any partial or total closure or other restriction of one or more lanes of traffic (in one direction of travel) using the Project Road, but excluding any Type C lane closures (as defined in Section 6 of Chapter 8 of the Traffic Signs Manual) and for the avoidance of doubt, traffic congestion or slow moving traffic on the Project Road shall not be considered in and of itself to be a partial or total closure of a lane of traffic.
Lane Closure means full or partial closure of any traffic lane in any portion of the Project and for any duration, including main lanes, ramps, direct connectors, frontage roads and cross roads. Law or Laws shall mean (a) any statute, law, code, regulation, ordinance, rule or common law,
Lane Closure means any Closure affecting a Traffic lane or lanes on a road, but excludes a Full Closure.