Change Order Form. The Change Order Form is the instrument by which adjustments in the Contract Price and Contract Time are effected pursuant to changes made in accordance with Case (a), Case (b) or Case (c) of Article 29 of the General Conditions or in accordance with Subparagraph (i) of Article 29 of the General Conditions. The Change Order Form shall be accompanied by a breakdown in the form prescribed in a specimen, which the Owner will supply to the Contractor. The Engineer shall certify to the amount of the adjustment. The Change Order Form shall be signed by the Contractor and the Owner. The breakdown is only for the purpose of enabling the Engineer and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Price. No condition, term, qualification, limitation, exception, exemption, modification, or proviso shall appear in the breakdown. The breakdown shall be in the exact form and language of the above-mentioned specimen. In the event any condition, term, qualification, limitation, exception, exemption, modification, or proviso shall appear in a breakdown, it shall be invalid.
Change Order Form. (for additional “out-of-scope” services) Supplemental Services are ad hoc services related to those set forth in this Agreement, but not specifically identified herein. Contractor shall provide Supplemental Services based the contract rates shown below or City may ask Contractor for a written quote consistent with the contract rates for each work request/project in lieu of Time & Materials. Any supplemental services must be authorized in advance, in writing, by the Director of Finance pursuant to Section 7 Change Order Procedure and Authorization in the form of Exhibit E. Job Title/Services Rate Senior PM $271/hour Senior Structural Engineer $271/hour Structural Engineer $180/hour CAD Tech $132/hour Survey Crew $204/hour Clerical Admin $120/hour Senior Network/RF Engineer $145/hour Network/RF Technician $95/hour Project Manager $130/hour Incremental Indoor AP Support Services $240 Per Access Point (AP), Per Year Incremental Outdoor AP Support Services $540 Per Access Point (AP), Per Year Miscellaneous Time & Material Cost/Discounts Subcontractor Services Cost +20% Incidental Materials and Equipment Cost +20% Ruckus Hardware Items 30% Discount off List Price* Ruckus Manufacturer Support 0% Discount off List Price Handling Fee for Pass through Items 5% Discount off List Price *an additional 5% off list pricing for bulk orders of Ruckus hardware and software over $100,000. In the event, the City negotiates directly with Ruckus, Contractor shall provide intermediary services to process, handle and coordinate equipment orders at the negotiated cost +5%.
Change Order Form. No instructions, either written or verbal, shall be construed as an order for changes unless it be in the form of a Change Order, bearing the signed approval of the COUNTY and the COUNTY’S representative and the signed acceptance of the CONTRACTOR’S signature to the order will not be mandatory. Change Orders shall describe or enumerate the work to be performed and state the price, if any, to be added to or deducted from the Agreement sum. Except as provided in the above paragraph, no change shall be made, unless in pursuance of a Change Order, and no claim for an addition to the Contract sum shall be valid unless so ordered. If the CONTRACTOR believes that any instructions, by drawing or otherwise, involves extra cost under his/her Agreement, he/she shall give the COUNTY written notice thereof and await instructions before proceeding to execute such work.
Change Order Form. The Construction Manager shall submit five (5) originals of the Change Order Form (OEF 425), signed by the Architect to the Owner’s Project Representative. The Change Order Form shall be executed by the Architect, Construction Manager and Owner. The Architect of Record for the Project shall certify in writing, and attach to the Change Order, that the cost of the requested change is fair, reasonable, and in proper proportion to the cost of the original work of the contract and shall recommend action thereon.
Change Order Form. Written for minor changes in the Work issued after execution of this Agreement; and
Change Order Form. To: Contract: (the “Contract”) Contract No.: Change Order No. Date: Defined terms used in this Change Order have the same meanings given to those terms in the Contract.
Change Order Form. The Parties will agree and document in a written amendment to the Work Order (each a “Change in Scope”) when there are any changes requested by Sponsor with regard to a Work Order.
Change Order Form. Consulting Agreement No. 05- Change Order Date: Consultant: Xxxxxxx X. Xxxxxxxxx Address: 0000 Xxxxxxx Xxxxx Xxxx/Xxxxx: Xxxxxxx, XX 00000 As provided in your Consulting Agreement with FedEx Corporation dated as of June 1, 2005, the following changes in the Work are made: This Change Order when signed by the Parties will have the following effect:
Change Order Form. Consulting Agreement Change Order Date: To Consultant: Address: City/State: As provided in your Consulting Agreement with FedEx Corporation dated as of , the following changes in the Work are made: This Change Order when signed by the parties will have the following effect:
Change Order Form. All Change Orders shall be executed in writing by Owner and Construction Manager, shall be in the form attached hereto as Exhibit A, Page 2, and shall contain full particulars of the changes, and any adjustments of the GMP or Contract Time. General Conditions of the Agreement Exhibit A Exhibits Effective Date: May 9, 2016 EXHIBIT A - CHANGE ORDER FORM DPC – STAGE II CHANGE ORDER PROJECT: CHANGE ORDER NO: TO: DATE: CONTRACT NO: CONTRACT DATE: You are hereby authorized to make the following changes in the Contract: PCI COR Date Description Total TOTALS FOR CHANGE ORDER $ The GMP was $ Net changes by previously authorized Change Orders $ The GMP prior to this Change Order was $ The GMP will be (increased) (decreased) (unchanged) by this Change Order in the amount of $ The new GMP, including this Change Order will be $ The time for completion of the Project will be (increased) (decreased) (unchanged) by ( ) days The date of Substantial Completion as of the date of this Change Order is Payment for this change shall fully compensate Construction Manager for all costs directly or indirectly related to this work and for any effect upon other Work under the Contract Documents except as may be otherwise expressly noted herein. Unless otherwise expressly provided for herein, all impact costs resulting from the performance of this Change Order are included herein and no other impact cost resulting from the performance of this Change Order shall be permitted. No extension of time for the performance of this Change Order Work or any other Work under the Contract Documents shall be allowed as a result of this Change Order, except as otherwise specifically provided above. All other terms and conditions of the Agreement between Owner and Construction Manager remain unchanged. OWNER: CONSTRUCTION MANAGER: By: _ Name: Title: Date: By: _ Name: Tile: Date: APPROVED BY CCR/CITY (AS NECESSARY): By: _ Name: Title: Date: EXHIBIT B - CHANGE ORDER PRICING
