Change Order definition

Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Change Order means a written instrument signed by Owner and Contractor stating their agreement upon all of the following: (1) a change in the Work; (2) the amount of the adjustment in the Contract Sum, if any, and (3) the extent of the adjustment in the Contract Time, if any.

Change Order means a written modification of the Contract between the Owner and Contractor, signed by the Owner, the Contractor and the A/E.

Examples of Change Order in a sentence

Should Buyer fail to install the Equipment pursuant to this Section, for reasons other than Supplier’s breach of its obligations hereunder or an Event of Force Majeure, Buyer shall pay Supplier the remaining milestones under the Milestone Payment Schedule; provided, however, that for [***] after Delivery, the Parties shall work together to re-schedule Supplier’s obligation to conduct the Performance Tests subject to an agreed Change Order.
This Agreement shall be amended or a Change Order shall be issued as necessary to reflect the foregoing provision.
The Supplier shall have the right to suspend the performance of the Agreement until the Parties have signed a mutually agreed Change Order or amendment reflecting the changes resulting from a Change of Law as stated herein.
Supplier shall not be obliged to proceed with any changes or extra work until the price of such change or extra work and its effects on the Equipment Delivery date, and Performance Guarantees have been agreed upon in a Change Order.
Should any such delay materially impair completion of the Work, then Supplier shall be entitled to a Change Order in accordance with Article 8 above.

More Definitions of Change Order

Change Order means a written amendment to the existing contract or a new contract from the Purchaser to the Contractor after the Effective Date of the contract requiring a change in any part of the Stores that may involve

Change Order means any written alteration in specifications, delivery point, rate of delivery, period of performance, price, quantity, or other provisions of any contract accomplished by mutual agreement of the parties to the contract.

Change Order means a written order to the Contractor, signed by the County, authorizing an addition, deletion or revision in the Work, or an adjustment in the Contract Amount or the Contract Time issued after execution of the Contract.

Change Order means the documents issued by au- thorized representatives of Purchaser and Supplier in common agreement after a Change has been re- quested by Purchaser or Supplier, and which docu- ments rule the modification of the Contract, in particular with respect to the Contract Price, specifications, ship- ment schedule, warranty, Delivery Date, etc.

Change Order means a written document ordering a change in the Contract Price or Contract Time or a material change in the Work.

Change Order has the meaning set forth in Section 5.3.

Change Order means and includes a written order to the Design/Builder signed by the Owner or Owner’s Representative and the Design/Builder and issued after the execution of this Agreement, authorizing a change in the Project and/or an adjustment in the Fixed Contract Price or the Contract Time.