General Project Scope Sample Clauses

General Project Scope. CM Services for the construction of the Aquatic Center and all related onsite and offsite improvements per project documents.
Sample 1
AutoNDA by SimpleDocs
General Project Scope. In general, the A/E will be required to provide architectural and engineering services necessary to modernize the Jelleff Community Center. The A/E will be required to provide all the design services necessary to implement the Project and to produce the required deliverables. A feasibility study is provided as Attachment A for informational purposes only. The design shall incorporate the following facilities and site amenities:
Sample 1
General Project Scope. The Project consists of the Remodel/Renovation and limited Historical Preservation/Restoration of the Xxxx Federal Courthouse Building. The Xxxx Building is composed of a three story structure with a partial basement and a partial Mezzanine. The footprint of the Building is approximately 256’x228’ with approximately 171,500 GSF. The basement has an approximate area of 32, 500 GSF of which approximately 9,250 will be separated by a security wall to continue to serve the adjacent Xxxxxx facility. The remaining 23,250 GSF will be incorporated into the MDC Xxxx Facility. The first level has approximately 56,500 GSF, the Mezzanine has approximately 7,500 GSF, the second level has approximately 46,000 GSF and the third level has approximately 29,000 GSF. The total approximate area to be remodeled/renovated for the MDC Xxxx Project is approximately 162,250 GSF. The work shall include completion of the security separation of Xxxx from the Xxxxxx Federal Building, new and separate utility systems including HVAC, Electrical including lighting/power and low voltage, IT, communications, security, and the disconnect and removal of the existing systems not designated to be reused. The installation of two new exit stairs and one elevator core if required within the building. The construction of a skylight system over the interior open courtyard. The renovation/remodel of approximately 162,250 GSF into classrooms, large event venues, library spaces, open student collaboration spaces, offices and other related college spaces including the structural modifications required to achieve the new program spaces. The repairs, cleaning and waterproofing of the exterior historical wall system. The repairs of the existing window. Any other work deemed to be required to achieve the MDC programs. The A/E and the CM selected will assist the MDC Xxxxxxx Campus & Facilities Staff in developing the Educational Specifications and Facilities list for the programs to be housed at the Xxxx Federal Courthouse Building. Any other work deemed to be required to achieve the MDC programs, which will include spaces such as classrooms, instructional facilities, laboratories, electronic classrooms, multipurpose facilities, common areas, exhibit spaces, meeting/conference facilities, offices, gallery spaces, fashion runway, student gathering spaces, study areas, library facilities, storage, campus support facilities, server rooms, among others) as well as the types of related spaces/infrastructure that...
Sample 1
General Project Scope. The scope of the Project is outlined in the Project Scope, attached as Exhibit A.
Sample 1
General Project Scope. In accordance with Section 14304 of the California Public Resources Code, projects of the Contractor (“Projects”) shall be directed toward providing opportunities to the public for the use of natural resources and environmentally important public lands and waters, while at the same time providing young men and women with an opportunity for personal development in a variety of basic skills. Projects shall be selected by mutual agreement of the City and Contractor on the basis of the environmental and natural resource benefits offered, the opportunities for public use, and the value of on-the-job training for corpsmembers. The City recognizes that the resources of the Contractor are limited, and the public service conservation work of the Contractor may be altered in priority from time to time. Examples of typical Projects which might be selected by agreement between the City and Contractor include landscaping, park maintenance, concrete repair, litter and graffiti abatement, recycling, steam cleaning, or emergency assistance such as preparing sand bags or road closures.
Sample 1
General Project Scope. The general project scope includes the survey, design, and real estate services for the construction of a new roundabout at the intersection of County Road 600 West and 750 North in the Town of McCordsville, Hancock County, Indiana, utilizing local funds. The CONSULTANT shall be responsible for performing the following activities: TASK 1. Topographic Survey Data Collection TASK 2. Roadway Design and Plan Development TASK 3. Bridge Design and Plan Development TASK 4. Utility Coordination TASK 5. Geotechnical Services TASK 6. Cemetery Development Plan TASK 7. Environmental Services TASK 8. Public Involvement TASK 9. Waters of US Report TASK 10. Environmental Permitting TASK 11. Special Investigations TASK 12. Right of Way Engineering and Plan Development TASK 13. Real Estate Acquisition Services TASK 14. Construction & Utility Relocation Phase Services TASK 15. Excluded Professional Services Remainder of this page left blank intentionally.
Sample 1
General Project Scope. A. This project is comprised of construction of one production well at the site including gravel site access drive, staging area, construction of drilling mud pits, and discharge control structures. Further, the project includes restoring the site by disposing of drilling mud and filling pits, removing rock check dams from discharge control structures and general grading to maintain site drainage. The well shall be constructed to such vertial tolerances to allow installation of future vertical lineshaft pumping equipment capable of delivering approximately 1000 gpm from the well.
Sample 1
AutoNDA by SimpleDocs

Related to General Project Scope

  • Project Scope The physical scope of the Project shall be limited to only those capital improvements as described in Appendix A of this Agreement. In the event that circumstances require a change in such physical scope, the change must be approved by the District Committee, recorded in the District Committee's official meeting minutes, and provided to the OPWC Director for the execution of an amendment to this Agreement.

  • Project Implementation 2. The Borrower shall:

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Project Timeline The Project Timeline establishes a start and end date for each Phase of the Project. Developed during the Initiate & Plan Stage and revised as mutually agreed to, if needed, the timeline accounts for resource availability, business goals, size and complexity of the Project, and task duration requirements.

  • Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.

  • Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.

  • Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.

  • Research Project 3.1 These Materials and Data will be used by Recipient's PI solely in connection with the Research Project, as named and described in the attached research application (insert Research Project name below):

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Project Summary The main objective of the LIFE GAIA Sense project is to demonstrate Gaiasense, an innovative “Smart Farming” (SF) solution that aims at reducing the consumption of natural resources, as a way to protect the environment and support Circular Economy (CE) models. More specifically, this project will launch 18 demonstrators across Greece, Spain and Portugal covering 9 crops (olives, peaches, cotton, pistachio, potatoes, table tomatoes, industrial tomatoes, grapes, kiwi) in various terrain and microclimatic conditions. They will demonstrate an innovative method, based on high-end technology, which is suitable for being replicated and will be accessible and affordable to Farmers either as individuals or collectively through Agricultural Cooperatives. Moreover, LIFE GAIA Sense aims to promote resource efficiency practices in SMEs of the agricultural sector and eventually, contribute to the implementation of the Roadmap to a Resource Efficient Europe. This project will demonstrate a method on how the farmer will be able to decide either to use or avoid inputs (irrigation, fertilizers, pesticides etc.) in a most efficient way, without risking the annual production. The focus is on the resource consumption reduction side of CE, and the results will be both qualitatively and quantitatively, considering the resources’ efficiency in agricultural sector.

Time is Money Join Law Insider Premium to draft better contracts faster.