Construction Progress Schedule. A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Construction Progress Schedule. Construction Progress Schedule.
Construction Progress Schedule. (a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring labor, materials, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments or take other remedies under the contract until the Contractor submits at the site; the required schedule.
Construction Progress Schedule. 7.3.1 The A/E shall review the Construction Progress Schedule for conformance with the Contract Documents, provide a copy of the Construction Progress Schedule and schedule of submittals to the Contracting Authority and Owner.
Construction Progress Schedule. Within ten (10) days of the Notice to Proceed, the Contractor shall submit to the Engineer a Preliminary Progress Schedule (“PPS”) and a Near Term Schedule (“NTS”) in the form and with the content required by the Specifications. Within forty- five (45) days of the Notice to Proceed, the Contractor shall submit to the Engineer the Overall Project Schedule (“OPS”) as required in the Specifications.
Construction Progress Schedule. Construction Progress Schedule prepared in accordance with this Contract including the dates assumed by CMR for the Design Professional’s completion of Construction Documents necessary to effect the Program.
Construction Progress Schedule. A schedule, as more fully defined in Paragraph2.1.5.2, prepared by the CM/GC (based, in part, upon the Owner‟s Program and the Design Professional‟s Preliminary Design and Construction Schedule), indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion, Occupancy and Final Completion.
Construction Progress Schedule. 6.5.1 The CM shall prepare and maintain a resource-loaded Construction Progress Schedule using the critical-path method of scheduling that provides the following information:
Construction Progress Schedule. A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion and shall have the meaning set forth in Section 2.1.5.2. The schedule will be developed to represent the CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to the Design Professional and the Board the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Board’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as those listed in 1.1.9.38 below. The Design Professional shall approve the form and adequacy of the Construction Progress Schedule. If it chooses, the Board shall have final approval authority of the form and adequacy of the Construction Progress Schedule. The CMR shall submit the Original Construction Progress Schedule no later than seven (7) days after the Pre-Construction Proceed Order Date. This first submittal of the Original Construction Progress Schedule and others to follow may, if the CMR chooses, be deemed “preliminary.” Until the Original Construction Progress Schedule is offered by the CMR as the “final” version, the CMR shall submit honed and updated “preliminary” Original Construction Progress Schedules as often as he sees to be fitting, and no less often than within seven (7) days of each request by the Design Professional, Board Representative, or Program Manager. Once submitted and approved in “final” form, the Original Construction Progress Schedule shall apply and be followed, and will not require revision for the submittal of an updated schedule unless provided for herein. So long as the Construction Proceed Order has been issued, the CMR shall without delay proceed with all portions of the Work it deems suitable and fitting to meet the requirements of the Contract Documents, regardless of the status of the schedule, whether preliminary or final.
Construction Progress Schedule. This Section includes administrative and procedural requirements for the preparation, submittal, and maintenance of the progress schedule, reporting progress of the Work, and Contract Time adjustments, including the following:
