Suspension. 19.2.1 If:
Suspension. Developer reserves the right, upon written notice to Connecting Transmission Owner and NYISO, to suspend at any time all work by Connecting Transmission Owner associated with the construction and installation of Connecting Transmission Owner’s Attachment Facilities and/or System Upgrade Facilities and/or System Deliverability Upgrades required for only that Developer under this Agreement with the condition that the New York State Transmission System shall be left in a safe and reliable condition in accordance with Good Utility Practice and the safety and reliability criteria of Connecting Transmission Owner and NYISO. In such event, Developer shall be responsible for all reasonable and necessary costs and/or obligations in accordance with Attachment S to the ISO OATT including those which Connecting Transmission Owner (i) has incurred pursuant to this Agreement prior to the suspension and (ii) incurs in suspending such work, including any costs incurred to perform such work as may be necessary to ensure the safety of persons and property and the integrity of the New York State Transmission System during such suspension and, if applicable, any costs incurred in connection with the cancellation or suspension of material, equipment and labor contracts which Connecting Transmission Owner cannot reasonably avoid; provided, however, that prior to canceling or suspending any such material, equipment or labor contract, Connecting Transmission Owner shall obtain Developer’s authorization to do so. Connecting Transmission Owner shall invoice Developer for such costs pursuant to Article 12 and shall use due diligence to minimize its costs. In the event Developer suspends work by Connecting Transmission Owner required under this Agreement pursuant to this Article 5.16, and has not requested Connecting Transmission Owner to recommence the work required under this Agreement on or before the expiration of three (3) years following commencement of such suspension, this Agreement shall be deemed terminated. The three-year period shall begin on the date the suspension is requested, or the date of the written notice to Connecting Transmission Owner and NYISO, if no effective date is specified.
Suspension. This Agreement shall be suspended upon any of the following events, and shall remain suspended until such event is rectified:
Suspension. Suspend or go out of a substantial portion of its business.
Suspension. NYSERDA, in its sole discretion, reserves the right to suspend any or all activities under this Agreement, at any time, when it discovers information that calls into question the Responsibility of the Contractor. In the event of such suspension, the Contractor will be given written notice outlining the particulars of such suspension. Upon issuance of such notice, the Contractor must comply with the terms of the suspension order. Contract activity may resume at such time as NYSERDA issues a written notice authorizing a resumption of performance under the Contract.
Suspension. The Interconnection Customer reserves the right, upon written notice to the Participating TO and the CAISO, to suspend at any time all work associated with the construction and installation of the Participating TO's Interconnection Facilities, Network Upgrades, and/or Distribution Upgrades required under this LGIA with the condition that the Participating TO’s electrical system and the CAISO Controlled Grid shall be left in a safe and reliable condition in accordance with Good Utility Practice and the Participating TO’s safety and reliability criteria and the CAISO’s Applicable Reliability Standards. In such event, the Interconnection Customer shall be responsible for all reasonable and necessary costs which the Participating TO (i) has incurred pursuant to this LGIA prior to the suspension and (ii) incurs in suspending such work, including any costs incurred to perform such work as may be necessary to ensure the safety of persons and property and the integrity of the Participating TO’s electric system during such suspension and, if applicable, any costs incurred in connection with the cancellation or suspension of material, equipment and labor contracts which the Participating TO cannot reasonably avoid; provided, however, that prior to canceling or suspending any such material, equipment or labor contract, the Participating TO shall obtain Interconnection Customer's authorization to do so. The Participating TO shall invoice the Interconnection Customer for such costs pursuant to Article 12 and shall use due diligence to minimize its costs. In the event Interconnection Customer suspends work required under this LGIA pursuant to this Article 5.16, and has not requested the Participating TO to recommence the work or has not itself recommenced work required under this LGIA on or before the expiration of three (3) years following commencement of such suspension, this LGIA shall be deemed terminated. The three-year period shall begin on the date the suspension is requested, or the date of the written notice to the Participating TO and the CAISO, if no effective date is specified.
Suspension. Anything contained in this Agreement to the contrary notwithstanding, the Company may by notice in writing to each Holder of Registrable Shares to which a Prospectus relates, delay, for up to 60 days (the “Delay/Suspension Period”), the filing or the effectiveness of any Registration Statement filed (or to be filed) under Section 2, 3 or 4 or require such Holder to suspend, for up to the Delay/Suspension Period the use of any Prospectus included in a Registration Statement filed under Sections 2, 3 or 4 if at the time of such delay or suspension: (a) the Company is engaged in a Material Transaction; (b) the Company’s board of directors determines that the disclosure required to be included in such Registration Statement could be materially detrimental to the Company or its then current business plans; (c) the Company reasonably believes that effecting the Registration or shelf takedown, as applicable, would materially and adversely affect an ongoing plan by the Company to engage in (directly or indirectly through any of its Subsidiaries) a Material Transaction; or (d) the Company is in possession of material non-public information the disclosure of which during the period specified in such notice the Company reasonably believes (as determined by the Company’s board of directors) would not be in the best interests of the Company; provided, however, that: (i) the Company may not invoke this right more than three times in any 18 month period; and (ii) the Company shall not register any securities for its own account or that of any other security holder during any such Delay/Suspension Period. The period during which such registration must remain effective shall be extended by a period equal to the Delay/Suspension Period. The Company may (but shall not be obligated to) withdraw the effectiveness of any Registration Statement subject to this provision. For purposes of this Section 10, a “Material Transaction” shall mean a transaction that exceeds twenty percent (20%) of the Company’s gross revenue for the last twelve (12) months and the Company and/or its Controlled Companies (as defined in the Shareholders Agreement) enter into an association agreement with other companies, merger, spin-off, consolidation, acquisition, partnership, profit-sharing agreements, or the sale of assets by the Company or by the Controlled Companies.
Suspension. The Employer may suspend an employee for just cause. Notice of suspension shall be in writing and shall set forth the reasons for the suspension.
Suspension. A. No regular, limited-term or probationary employee shall be suspended except for reasonable cause.
Suspension. Records of suspension are to be removed from an Employee’s personnel file after eighteen (18) months from the date of discipline, provided that the Employee has remained discipline free during that period, except in the case of incidents involving residents in which case the record will remain on file if the complaint is not reversed through settlement or arbitration. Leaves of absence in excess of thirty (30) continuous calendar days will not count towards the eighteen (18) month period noted above.
