Diligent Performance Sample Clauses

Diligent Performance. With respect to any duty or obligation imposed on a Party by this Agreement, unless a time limit is specified for the performance of such duty or obligation, it shall be the duty or obligation of such Party to commence and perform the same in a diligent and workmanlike manner and to complete the performance of such duty or obligation as soon as reasonably practicable after commencement of performance.
AutoNDA by SimpleDocs
Diligent Performance. (a) Subcontractor agrees to commence, pursue diligently and complete the work in such sequence and order and according to such schedules as Contractor shall establish from time to time during the course of the work, and shall perform the work so as not to delay any other trades or contractors, time being of the essence of this Subcontract. Any written dates furnished by the Subcontractor and approved by Contractor and Owner for delivery of materials, samples, shop drawings, etc., shall become a part of this Subcontract. Subcontractor shall furnish information requested by the Contractor in connection with monitoring and updating the Project schedule and shall immediately notify Contractor in writing of any interruption of the work or late delivery which causes or may cause a delay in Subcontractor's performance. No extension of completion date shall be permitted unless approved in writing by the Contractor and Owner, and Subcontractor shall be responsible for any losses or penalties incurred by Contractor as a result of delays in completing Subcontractor’s work. If Contractor determines that the Subcontractor is behind schedule or will not be able to maintain the schedule, Subcontractor shall submit a remedial plan to recover, shall work overtime, shift work, or work in an altered sequence, if deemed necessary, in the judgment of the Contractor to maintain the progress of the work. Any such overtime, acceleration, shift or altered sequence work required to maintain progress or to complete the work on a timely basis shall be at Subcontractor's expense and shall not entitle Subcontractor to an extension of time or additional compensation. Contractor may supplement Subcontractor's forces, at Subcontractor's expense, if deemed necessary by the Contractor to maintain the Project schedule. Subcontractor shall be liable to the Contractor for any delay or damages, including consequential or liquidated damages, threatened or assessed against the Contractor to the extent caused by the Subcontractor.
Diligent Performance. During his Engagement, the Director shall faithfully and diligently perform such duties and exercise such powers in relation to the Company as are specified herein and as may from time to time be duly vested in him by the Company. The Director shall perform his duties with a good manager’s care so as to embody and enhance the Company’s reputation for excellence.
Diligent Performance. The Society shall operate and maintain the Pound in a good and workmanlike manner and shall otherwise conduct its operations under this Agreement faithfully and diligently and in accordance with all terms and conditions of this Agreement.
Diligent Performance. During the Term, each Investigator will use diligent efforts to perform the Research in accordance with the timetable set forth in the Proposal, pursuant to his or her Investigator Research, and in accordance with the applicable Investigator Budget. The Investigator and the Investigator Institution will not subcontract any of its obligations under the Investigator Research, except as disclosed in the Investigator Research, without the prior written consent of FLQ, which consent may be withheld in FLQ’s sole discretion. If Investigator desires to perform any human clinical studies as part of the Investigator Research, the Investigator must first receive FLQ’s written consent, which FLQ may withhold in its sole discretion. Investigator is solely responsible for acquiring all regulatory and IRB approvals necessary to perform any approved clinical research.
Diligent Performance. Each Party shall use Commercially Reasonable Efforts during the Research Term to perform that part of the Research Program for which such Party is responsible pursuant to the terms and conditions of this Agreement, and to complete such tasks in compliance with the Research Plan. BMS shall use Commercially Reasonable Efforts to Develop or Commercialize at least one Licensed Compound or Licensed Product. During the Combined Period, such Commercially Reasonable Efforts shall be satisfied if BMS uses Commercially Reasonable Efforts to conduct the Development of at least one Licensed Compound to obtain ECN Approval thereof. During the period that BMS is funding at least * (*) FTEs of AMRI that are working on the Research Program, BMS shall be deemed to be using such Commercially Reasonable Efforts and to have satisfied its obligation under this Agreement to use Commercially Reasonable Efforts to Develop or Commercialize at least one Licensed Compound or Licensed Product. After the Combined Period, BMS shall use Commercially Reasonable Efforts to conduct the Development, manufacturing, and obtain Approval of at least one Retained Product for at least one Reserved Indication in the United States. After Approval in the United States of a Retained Product for an Indication, BMS shall use Commercially Reasonable Efforts to Commercialize each such Retained Product for each such Indication in the United States. With respect to countries outside the United States, after the Combined Period BMS shall use Commercially Reasonable Efforts to obtain Approval of at least one Retained Product for at least one Reserved Indication in each Major Market Country other than the United States unless Commercialization of such Product in any such Major Market Country is not warranted because of Approval and/or Commercialization issues in such country that are not caused by BMS or a product being marketed or to be marketed by BMS in such country. As reasonably requested by AMRI, BMS shall provide AMRI with information as to why Commercialization is not warranted. In the event that BMS is complying with BMS’ obligations under this Section 8.2 with respect to one Retained Product, then all Reserved Indications shall remain Reserved Indications. In addition, if BMS is meeting its obligations under this Section 8.2 with respect to one Retained Product, then BMS shall not be obligated to Develop or Commercialize any other Retained Product.
Diligent Performance. Time is of the essence of the Contract. Supplier agrees to prosecute the Work with all due diligence and shall effect delivery of the Goods and/or perform the Services by the date(s) specified in the Contract.
AutoNDA by SimpleDocs
Diligent Performance. Executive accepts the employment described in Article I of this Agreement and agrees to devote his full time and efforts to the faithful and diligent performance of the services described herein, including the performance of such other services and responsibilities as the Company may, from time to time, stipulate. Notwithstanding any provision in this Agreement to the contrary, Executive shall be permitted to serve as a member of the board of directors of other for-profit or non-profit organizations, so long as such memberships do not interfere, individually or in the aggregate, with the performance of the Executive’s duties hereunder and would not reasonably be expected to compete with the business of the Company.
Diligent Performance. During the Term, Mr. Park shall faithfully and diligently perform such duties and exercise such powers in relation to the Company as are specified herein, and as may from time to time be duly vested in him by the Company. Mr. Park shall perform his duties in a professional manner so as to embody and enhance the Company's reputation for excellence.

Related to Diligent Performance

  • Product Performance Contractor hereby warrants and represents that the Products acquired by the Authorized User under the terms and conditions of this Contract conform to the specifications, performance standards and documentation in the Authorized User Agreement., and the documentation fully describes the proper procedure for using the Products. Contractor further warrants and represents that if the Products acquired by the Authorized User pursuant to an Authorized User Agreement under this Contract include software application development, software application customization, software programming, software integration or similar items (“Software Deliverables”) then such Software Deliverables shall be free from defects in material and workmanship and conform with all requirements of the Contract and Authorized User Agreement for the warranty period of one (1) year from the date of acceptance of the completed project (“Project warranty period”). Contractor also warrants that the Products, in the form provided to the Authorized User, do not infringe any copyright, trademark, trade secret or other right of any third party.

  • Work Performance All work in performance of this Lease shall be done by skilled workers or mechanics and shall be acceptable to the RECO. The RECO may reject the Lessor’s workers 1) if such are unlicensed, unskilled, or otherwise incompetent, or 2) if such have demonstrated a history of either untimely or otherwise unacceptable performance in connection with work carried out in conjunction with either this contract or other Government or private contracts.

  • Excused Performance 6.1 Notwithstanding the occurrence of a Force Majeure Event, in which case Clause 17 will govern, BT will not be liable for any failure or delay to perform any of its obligations under this Agreement (including any of its obligations to meet any Service Levels) to the extent that BT’s failure or delay in performing arises as a result of:

  • Full Performance The Owner and the Contractor hereby agree to the full performance of the Contract Documents.

  • Strict Performance Failure by any party to this Contract to insist in any one or more cases upon the strict performance of any of the terms, covenants, conditions, or provisions of this Contract shall not be construed as a waiver or relinquishment of any such term, covenant, condition, or provision. No term or condition of this Contract shall be held to be waived, modified, or deleted except by a written amendment signed by the parties hereto.

  • Unsatisfactory Performance All work performed by the Contractor is expected to be done in the most expeditious and professional manner as specified in Section 5 of this document, while also complying with the workmanlike standard clause contained at Section 5.4.1.

  • Lawful Performance Vendor shall abide by all Federal, State and Local Laws, Ordinances, Regulations, and Statutes as may be related to the performance of duties under this agreement. In addition, all applicable permits and licenses required shall be obtained by the vendor, at vendor’s sole expense.

  • EVALUATING PERFORMANCE 7.1 The Performance Plan (Annexure A) to this Agreement sets out:

  • Prompt Performance All actions required to be taken by any Party under this Agreement shall be performed within the time prescribed for performance in this Agreement or if no period is prescribed, such actions shall be performed promptly.

  • Substantial Performance This Contract shall be deemed to be substantially performed only when fully performed according to its terms and conditions and any written amendments or supplements.

Time is Money Join Law Insider Premium to draft better contracts faster.