Progress Schedule means a schedule of the Work, in a form satisfactory to Owner, as further set forth in Section 3.02.
Progress Schedule means the Progress Schedule established by the CONTRACTOR and approved by the Engineer-in-Charge for completion of the work(s) within the time schedule in accordance with the provisions hereof and failing such Progress Schedule, shall mean the Progress Schedule established by the Engineer-in-Charge in accordance with the provisions hereof.
Progress Schedule means the updated Project Schedule which is revised monthly showing actual times of completion for various portions of the Work and includes revised completion dates for uncompleted Work, as well as reflecting Change Order work, revisions and modifications to the Work.
Examples of Progress Schedule in a sentence
Contractor may revise the Work Progress Schedule when in Contractor’s judgment it becomes necessary for the management of the Work.
The Contractor shall update the Work Progress Schedule and the Submittal Register monthly, as a minimum, to reflect progress to date and current plans for completing the Work, and submit a paper and electronic copy of the update to the A/E and ODR as directed but as a minimum with each request for payment.
The Contractor is responsible for providing Samples of sufficient size for test purposes and for coordinating such tests with the Work Progress Schedule to avoid delay.
The Contractor shall provide with each time extension request a quantitative demonstration of the impact of the delay on Project completion time, based on the Work Progress Schedule.
Unless otherwise indicated in the Contract Documents, the Work Progress Schedule shall be based upon a computerized Critical Path Method (CPM) with fully editable logic.
More Definitions of Progress Schedule
Progress Schedule means a version of the schedule for the Work provided by the Contractor subsequent to the Guaranteed Project Schedule, pursuant to the requirements of the Contract related to issues such as time extensions, claims, payments, tardiness and recovery.
Progress Schedule means the time schedule of progress of work.
Progress Schedule means the schedule that establishes completion dates for activities required in the contract documents, and interim completion dates, including revisions and updates to that schedule.
Progress Schedule has the meaning given in the Works Coordination Agreement.
Progress Schedule. Means Any schedule issued or approved by the Owner for the performance of the Work, including, without limitation, Project or Work milestones, deadlines or delivery dates. “Project” Means As defined in Part I, Section 3.1 “Project Safety Program” Means A safety program established at the Project Site initiated and supervised by the Owner’s Representative. “Project Safety Representative” Means As described in Part V.A, Section 2.9 “Project Schedule” Means The Owner’s schedule and milestones for the entire Project. “Project Site” Means As identified in Part I, Section 3.2. “Protest Work” Means As described in Part II, Section 5.5. “RAP” Means Remedial Action Plans. “RE” Means Resident Engineer. “RE’s Principal” Means The individual for whom the Owner has contracted to act as the principal representative of the Resident Engineer for the Project, as identified in Part I, Section 4.2.3. “Reporting Period” Means The one (1) month period commencing on the Commencement Date and each month thereafter during the term of the Contract, for which period the Construction Manager or Resident Engineer shall report to the Owner on the status of the Project. “Representatives” “Request for Information (RFI)” Means Means The employees, agents, servants, officers, directors, members, independent contractors and subcontractors of a person or entity. A request for additional information or clarification to be provided by the Contractor. Such request should be made within appropriate time to allow an answer to be provided by the Consultant before the work takes place. “Requisition” Means A request for payment, to be submitted to the Owner’s Accounts Payable Department by the Contractor not more than once per month, setting forth in detail, for the billing period for which partial payment is requested, the amount requested and Work performed during the billing period. “Resident Engineer” Means The entity or person contracted by the Owner to perform construction supervision services for the Project as identified in Part I, Section 4.2. “Retainage” Means Any sum withheld from any payment to the Contractor including, without limitation, any set percentage identified in Part I, Section 1.9, subject to the provisions of Part II, Article 4 and Part II, Article 11. “Retainage Payment Date” Means The date identified in Part I, Section 1.10, by which any Retainage identified in Part I, Section 1.9 will be paid to the Contractor, subject to the provisions of Part II, Article 4 and Part II, ...
Progress Schedule means the schedule approved by the County that identifies and assigns durations to activities that must be completed in order to complete the entire Work within the Contract Time and which is used to measure the Contractor’s performance.
Progress Schedule. As set forth in Exhibit B hereto.