Work Progress Schedule definition

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.
Work Progress Schedule or “WPS” shall have the meaning given in Paragraph 5.3.1.
Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that coordinates and integrates activities of the Project, including Contractor’s services, Design Professional’s services, the work of other consultants, suppliers, and Owner’s activities with the anticipated construction schedules for other contractors. The Work Progress Schedule accurately indicates all necessary and appropriate revisions, including a Longest Path impact analysis, as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.

Examples of Work Progress Schedule in a sentence

  • Owner has no duty to make progress payments unless accompanied by the updated Work Progress Schedule.

  • Contractor may revise the Work Progress Schedule when in Contractor’s judgment it becomes necessary for the management of the Work.

  • Contractor shall provide with each Time Extension Request a quantitative demonstration of the impact of the delay on project completion time, based on the Work Progress Schedule.

  • Contractor shall submit electronic and paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of Contractor’s actual plans for its completion.

  • Unless otherwise indicated in the Contract Documents, the Work Progress Schedule shall be computerized Critical Path Method (CPM) with fully editable logic.


More Definitions of Work Progress Schedule

Work Progress Schedule has the same meaning as defined in UGC Section 1.49.
Work Progress Schedule means the initial and subsequent updated t ime schedules prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.
Work Progress Schedule means the schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Special Conditions, if any, and the UGC, for design and construction of the Project, reflecting the CMR’s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work. The Work Progress Schedule may subsequently modified by mutual agreement between TFC and CMR to reflect any refinement in its requirements.
Work Progress Schedule means the CPM Schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Agreement, the Special Conditions (if any), and the UGC, reflecting the Contractor’s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work and updated as required in Paragraph 7.3.
Work Progress Schedule means the schedule for the Completion of the Work and parts thereof, as reasonably approved by Lender in writing. The Work Progress Schedule shall be attached hereto as Exhibit E at such time as it has been prepared by Borrower and reasonably approved by Lender in writing.
Work Progress Schedule with respect to a Development Loan, the schedule for the Completion of the related Work and parts thereof, as approved by Lender in writing.