Payment Does Not Imply Final Acceptance of Work Clause Samples

Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay.

Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay. Background The Judicial Council of California (Council), chaired by the Chief Justice of California, is the chief policy making agency of the California judicial system. The California Constitution directs the Council to improve the administration of justice by surveying judicial business, recommending improvements to the courts, and making recommendations annually to the Governor and the Legislature. The Council also adopts rules for court administration, practice, and procedure, and performs other functions prescribed by law. The Administrative Office of the Courts (AOC) is the staff agency for the Council and assists both the Council and its chair in performing their duties. AOC Classification and Compensation Study The AOC has undergone a significant downsizing and restructuring, and has not conducted an in-depth, agency-wide review of the classification and compensation structure in recent years. The AOC Human Resources Services Office (HRSO) provides direct classification and compensation support for employees of the AOC, as well as employees of the California Supreme Court and the Courts of Appeal, and, upon request, the Superior Courts of California. This project is a comprehensive study of only AOC positions, classifications, and compensation. The Chief Justice sets compensation rates for all AOC employees per Cal. Const., Art VI, §6; Gov. Code, §19825(b). Employees of the AOC are not represented by unions. Currently, the AOC has 21 offices spread over four divisions. There are approximately 725 incumbents in 183 job classifications across various functional areas such as legal, finance, administration, education, information systems, court services, human resources, governmental affairs, and security. The AOC seeks to consolidate classifications no longer deemed essential in meeting the business needs of the organization with the goal of streamlining the classification system. The AOC’s salary listing, including links to classification specifications, is available through the foll...

Payment Does Not Imply Final Acceptance of Work. The granting of any payment by the AOC as provided in this Exhibit shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay. Consultant shall, as authorized, provide the Work as specified in the Statement of Work (SOW) and as may be further specified in Work Orders authorized under this Agreement. The dates of performance and schedule applicable to the provision of the Work under this Agreement will be provided in individual issued Work Orders. Consultant agrees to provide or perform, as specified in this Agreement, the following Work set forth in this section, and as further elaborated in Work Orders when authorized under this Agreement, as well as any other services that are necessary, normal, customary, or incidental to the performance of Consultant’s responsibilities. Work Order may contain additional terms and conditions regarding the Work that is applicable only to the issued Work Order, however, no provision of the Work Order may act to modify or may conflict with the terms con conditions of this Agreement. This scope of work includes, but is not limited to the following: 1. Provide and/or assist the AOC with any of the following specific Construction Health and Safety Services: 1.1. Conduct Safety and Health Assessments 1.2. Identify Industrial Hazards 1.3. Conduct Activity Hazard Analyses (AHA) on specific industrial or manufacturing processes, 1.4. Prepare Emergency Action Plans 1.5. Develop health and safety plans 1.6. Develop accident prevention plans 2. Provide and/or assist the AOC in providing any of the following specific General Industry Health and Safety Services: 2.1. Conduct Safety and Health Assessments 2.2. Identify Industrial Hazards 2.3. Develop Accident Prevention Plans