Payment Does Not Imply Acceptance of Work. The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
Payment Does Not Imply Acceptance of Work. The granting of any payment by the AOC, or the receipt thereof by the Contractor, shall in no way lessen the liability of the Contractor to correct unsatisfactory work in connection with this Agreement.
Payment Does Not Imply Acceptance of Work. The granting of any progress payment or payments by STA, or the receipt thereof by the Contractor, shall not constitute in any sense acceptance of the Work performed by Contractor, or any portion thereof, and shall in no way lessen the liability of the Contractor to re-perform Work which does not conform to this Agreement, though the character of such Work may not have been apparent or detected at the time such payment was made.
Payment Does Not Imply Acceptance of Work. The JBE’s payment will not relieve Contractor from its obligation to replace unsatisfactory Work, even if the unsatisfactory character of such Work may have been apparent or detected at the time such payment was made. Work, Data, or components that do not conform to requirements of this Agreement will be rejected, and will be replaced by Contractor, without delay or additional cost to the JBE.
Payment Does Not Imply Acceptance of Work. The granting of any payment by the Judicial Council, or the receipt thereof by the Criteria Architect, shall in no way lessen the liability of the Criteria Architect to correct unsatisfactory work in connection with the Services. Services that do not conform to the requirements of this Agreement may be rejected by the Judicial Council and in such case the Criteria Architect must correct the delivery of Services without delay.
Payment Does Not Imply Acceptance of Work. The granting of any payment by the State as provided in this Exhibit C shall in no way lessen the liability of the Contractor to replace unsatisfactory Work or Material, even if the unsatisfactory character of such Work or Material may not have been apparent or detected at the time such payment was made. Materials, Data, components, or workmanship that do not conform to Exhibit D, Work to Be Performed, shall be rejected and shall be replaced by the Contractor without delay.
Payment Does Not Imply Acceptance of Work. No payment shall in any way lessen the liability of Consultant to remedy or replace unsatisfactory work, service, products, equipment, or materials, if the unsatisfactory character of such work, service, products, equipment or materials was not detected at the time of payment. Service, products, materials, equipment, components, or workmanship that do not conform to the requirements of this Contract may be rejected by the District and in such case must be remedied or replaced by Consultant without delay at no additional cost to the District. Nothing in this Section shall preclude, limit, or waive any other remedy or remedies available to the District.
Payment Does Not Imply Acceptance of Work. Payment does not imply acceptance of Consultant’s invoice, Goods, Services, or Deliverables. Consultant shall immediately refund any payment made in error. The Council shall have the right at any time to set off any amount owing from Consultant to the Council against any amount payable by the Council to Consultant under this Agreement.
Payment Does Not Imply Acceptance of Work. The granting of any payment by the Judicial Council, or the receipt thereof by the Contractor, shall in no way lessen the liability of the Contractor to correct any errors in or deficiencies identified in Services provided. Release of Claims
Payment Does Not Imply Acceptance of Work. The granting of any payment by the AOC, or the receipt thereof by Contractor, shall in no way alter the obligation of Contractor to remedy unsatisfactory performance of the Services. Services that do not conform to the requirements of this Agreement, in the AOC’s judgment, may be rejected by the AOC. In such case, Contractor must remedy the unsatisfactory performance without delay to bring it into conformance with this Agreement. END OF EXHIBIT