DETERMINATION AND EXTENSION OF CONTRACT TIME Sample Clauses

DETERMINATION AND EXTENSION OF CONTRACT TIME. The number of calendar or working days allowed for completion of the Work shall be stated in the contract and shall be known as the CONTRACT TIME.
Sample 1Sample 2Sample 3See All (26)
AutoNDA by SimpleDocs
DETERMINATION AND EXTENSION OF CONTRACT TIME. ‌ The number of Calendar or Working Days allowed for completion of the Work shall be stated in the proposal and Contract and shall be known as the Contract Time. Should the Contract Time require extension for reasons beyond the CMR’s control, it shall be adjusted as follows:
Sample 1
DETERMINATION AND EXTENSION OF CONTRACT TIME. CONTRACT TIME The Department shall determine and specify the contract time in the Notice to Proceed. The Date of completion shall be the date that the Department finds the work acceptable under the contract documents and that the Contractor has fully performed the work under the contract. The work on the contract will be considered substantially complete when the project has met the intention of the plans, as reasonably determined by the Engineer or the Consulting Engineer. When the Engineer or the Consulting Engineer considers the project substantially complete, the Department will discontinue the contract time charges prior to its final acceptance of the work.
Sample 1
DETERMINATION AND EXTENSION OF CONTRACT TIME. The T/LPA will provide the Contract Time in the Advertisement, in Working Days, Days, or Mandatory Completion Date. For Working Day Projects, the Project Manager will provide the Contractor with a weekly statement showing the Contract Time, the number of Working Days used, the accumulated Working Days charged, and the number of Working Days remaining to complete the Work. The Contractor shall have three (3) Days after receipt of the weekly statement to object in writing to the weekly statement, setting forth the specific dates and justifications for the objection. If the Project Manager finds that the Contractor’s objection is valid, or if there is an error, then the Project Manager will issue corrected weekly statement(s). If the Project Manager determines that the objection is not valid the Project Manager will notify the Contractor in writing. If the Contractor continues to object to the weekly statement then the Contractor may file a Notice of Intent to Claim. If the Contractor fails to timely object, the weekly statement is deemed Accepted by the Contractor. The Contractor is not entitled to a Partial Suspension, at its own request, when any of the conditions below apply:
Sample 1
DETERMINATION AND EXTENSION OF CONTRACT TIME. CONTRACT TIME The initial term of this contract is one calendar year. Xxxxxxx Xxxx: This contract may be renewed upon the mutual written consent of the Department and the Vendor with the approval of the Attorney General’s Office only as to form. Any request for renewal must be submitted to the Department 30 days prior to the expiration date of the initial contract term or appropriate renewal term. A contract renewal shall be in accordance with the terms and conditions of the original contract. Renewal of this contract is limited to two successive one-year periods. Automatic renewal of this contract is prohibited. Reasonable Time Extension: At the sole discretion of the Department, and with the approval of the Attorney General’s Office only as to form, this contract may be extended for a reasonable time after the initial contract term or after any renewal term as may be necessary to obtain a new contract or renew this contract. Any reasonable time extension shall not exceed 12 months. The Vendor may avoid a reasonable time extension by providing the Department with written notice of its desire to terminate this contract 30 days prior to the expiration of the then-current term. During any reasonable time extension period, the Vendor may terminate this contract for any reason upon giving the Department 30 days written notice. Automatic extension of this contract is prohibited.
Sample 1
DETERMINATION AND EXTENSION OF CONTRACT TIME. Delete this subsection in its entirety and substitute the following: The work for this Contract includes work under Defined Work Pay Items. All work under Defined Work Pay Items shall be completed no later than December 10, 2021.
Sample 1
DETERMINATION AND EXTENSION OF CONTRACT TIME. Delete this subsection in its entirety and substitute the following: The Contractor is advised that short duration halts to work at the Jamestown Plaza may be directed by the State Police for security reasons. The Contractor shall comply with any requests by the State Police or the RITBA or their agents to temporarily halt work and have all personnel leave the plaza site. Where appropriate under the provisions of this subsection, extensions or reductions to the Contract Time may be provided by Change Order, however, such extensions or reductions will be allowed only to the extent that the increase or decrease in the Work or delays of the types indicated herein affect current controlling operations and the overall Completion. Increases or decreases in Work or such delays that do not affect the overall completion are not to be the basis for reduction or extension of Contract Time. Extensions of Contract Time will not be granted under this subsection where it is determined by the Engineer that the Contractor could have avoided the circumstances which give rise to his requesting such extensions. If the Contractor is delayed in completion of the Work by reason of changes made under Subsection 104.02, or by any act of the Contractor consistent with Subsection 105.10, or due to the discovery of archaeological finds consistent with Subsection 107.11, or the discovery of hazardous substances, or by any act of the Engineer or of the Authority not contemplated by the Contract, any extension of Contract Time commensurate with the delay in overall completion of the Contract thus caused will  be granted and the Contractor is relieved from any claim. The Contractor’s plea that insufficient time was specified is not a valid reason for extension of time. The Authority, in determining an extension of time, may, at its discretion, take into consideration any delay or delays caused by conditions beyond its control, and without the fault of the Contractor, such conditions including, but not limited to the order, decree, or judgment of any court of judge thereof, fire, other casualty, strikes, lockouts, or acts of God. The extended time for completion shall then be in full force and effect, the same as though it were the original time for completion.
Sample 1
AutoNDA by SimpleDocs

Related to DETERMINATION AND EXTENSION OF CONTRACT TIME

  • EXTENSION OF CONTRACT The Director of Procurement Services may, with the consent of the contractor extend the Contract period beyond the indicated expiration date.

  • DETERMINATIONS AND NOTIFICATIONS IN RESPECT OF NOTES AND INTEREST DETERMINATION (a) The Agent shall, unless otherwise specified in the applicable Final Terms, make all the determinations and calculations which it is required to make, if any, under the Conditions, all subject to and in accordance with the Conditions.

  • Determination of Agreement 29. (1) In any of the following events namely if —

  • Exceptions and Extension of Payment Due Date NYSERDA has determined that, notwithstanding the provisions of Sections 504.3 and 504.4 of this Exhibit, any of the following facts or circumstances, which may occur concurrently or consecutively, reasonably justify extension of the Payment Due Date:

  • Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.

  • CONDITIONS OF SETTLEMENT, EFFECT OF DISAPPROVAL, CANCELLATION OR TERMINATION 9.1 The Effective Date of this Settlement Agreement shall not occur unless and until each of the following events occurs and shall be the date upon which the last (in time) of the following events occurs:

  • Conclusion of Contract Within 30 days after the termination, cancellation, expiration or other conclusion of the Contract, the Contractor must, at no cost to the County, return all County Information to the County in a format defined by the County Project Officer. The County may request that the Information be destroyed. The Contractor is responsible for ensuring the return and/or destruction of all Information that is in the possession of its subcontractors or agents. The Contractor must certify completion of this task in writing to the County Project Officer.

  • EXPIRATION DATE AND EXTENSION This Contract expires January 31, 2023, unless it is terminated sooner pursuant to Article XX of the General Terms and Conditions, which are incorporated into this Contract by reference. This Contract may be extended up to three additional one-year periods upon request of Sourcewell and with written agreement by the Contractor, not to exceed a total of four years.

  • Rescission and Early Termination of Contract The Illinois Commerce Commission is considering rescission and early termination of contract regulations that may afford you opportunities within certain parameters to rescind or terminate your contract without incurring an early termination fee. In addition, your DSP’s tariff (which is on file with the Illinois Commerce Commission) may contain provisions regarding penalty-free rescission periods. DES will comply with all applicable provisions and regulations concerning rescission and early termination of contract. Shortly after your election to take service from DES, your DSP should provide you an enrollment notice informing you of any rescission rights you may have and the last day for making a request to rescind. If you rescind this Agreement within the timeframe specified by your DSP, your enrollment with DES will be cancelled without penalty to you. Upon rescission in accordance with applicable law, this Agreement will be considered cancelled and neither party shall have any further obligation hereunder to each other. If you do not rescind this Agreement, you still may terminate the Agreement without any termination fee or penalty within 10 business days after the date of the first xxxx issued to you under this Agreement by calling DES toll-free at 000-000-0000 to let DES know to terminate this Agreement. You may terminate a residential electric supply agreement in this manner only one time in any 12 month period. Upon termination, you will remain responsible for all obligations, including payment for Retail Power and related costs and charges, incurred under this Agreement prior to the effective date of termination, including any applicable termination fee.

  • C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.

Time is Money Join Law Insider Premium to draft better contracts faster.