IN THE WORK Sample Clauses

IN THE WORK. Changes in the Work which are within the general scope of this Agreement may be accomplished by Change Order without invalidating this Agreement.
IN THE WORK. § 7.1 The Owner may make changes in the Work. Upon receipt of a notice of change to the work issued after the execution of a Work Order, the Contractor shall promptly notify the Subcontractor of such Modification. Unless otherwise directed by the Contractor, the Subcontractor shall not thereafter order materials or perform Work that would be inconsistent with the changes contemplated by the owner.
IN THE WORK. Subject to the terms of the Prime Contract, Contractor shall have the rights and power to request a change in the Sublet Work. Should Contractor, at any time during the progress of the Work, request any changes in the Scope of the Sublet Work, Subcontractor shall within a reasonable time thereafter submit an itemized estimate reflecting any cost changes required to make the changes. Such itemized estimate shall be furnished in sufficient detail that Contractor can distinguish the direct labor man-hours and labor costs, direct materials, direct equipment, applicable labor markups for employer labor burdens and benefits, and allocation of home office overhead and profit and other costs and expenses. All elements of potential costs are subject to negotiation; however, in the event agreement cannot be reached on estimated cost, Subcontractor reimbursement will be limited to actual costs plus 10% markup. It is directly understood and agreed, regardless from whom orders maybe taken for changes in the Scope of the Work, that no such changes are to be made except by a written Subcontract or Work Release or Change Order issued by an authorized corporate officer signatory of Contractor and then only when such order sets forth the amount of any addition or deduction and is signed by both parties thereto. In addition to a General Contractor Corporate officer of the Corporation, authorized signatures shall be stated on the assigned Work Release or subcontract or change order. If Subcontractor initiates a substitution, deviation or change which affects scope of Work or the Sublet Work or causes expense to Contractor, Subcontractor shall be liable for the expenses thereof. Notwithstanding anything herein to the contrary, Contractor may, pursuant to the requirements of the Prime Contract, order Subcontractor to proceed with changes for which final price and/or time have not yet been determined. Subcontractor shall proceed with the Work in accordance with directive of Contractor, in the absence of an agreement between Contractor and Subcontractor on the proper change to the amount or the time for the performance of any Work Release because of a change in the Work, Subcontractor may treat the matter as a claim. In such event, the Subcontractor shall be entitled to recover only the amount by which its direct costs have reasonably increased over the direct cost of performing the Work without the change to the Work, plus (10%) (5% on its Subcontractor’s work) of direct cost to...
IN THE WORK. 6.1 Adjustments to the Final Guaranteed Maximum Price on account of changes in the Work may be determined by any of the methods listed in Section 7.3.3 of AIA Document A201–2007, General Conditions of the Contract for Construction, subject to the provisions hereof. It is understood and agreed that refinement and detailing will be accomplished from time to time with respect to the Drawings and Specifications set forth in the Contract Documents. Notwithstanding any other provision hereof, no adjustment to the Cost of the Work, Contractor’s Fee, FGMP, the date required for Substantial Completion, or the Interim Completion Dates, shall be made unless (i) such refinement or detailing results in material changes in the Scope of the Work, quality, function, and or intent of the Drawings and Specifications not reasonably inferable or actually anticipated by Contractor in its reasonable judgment, industry standard practices, experience and expertise and (ii) such adjustment to the Cost of the Work, the Contractor’s Fee, the FGMP, the date required for Substantial Completion, or an Interim Completion Date is first approved in writing by the Owner by Change Order as described in Document A201, Article 7.
IN THE WORK. The Employer agrees to have in place and procedures to deal with violence in the workplace. The policies will address the prevention of violence, the management of violent situations, and support to employees who have faced violence. The parties agreed that if incidents involving abusive client action occur, that such action will be recorded and reviewed at the Occupational Health and Safety Committee. Reasonable steps within the control of the Employer will be followed to address the legitimate health and safety concerns of employees presented in that form. The Hospital, with the employees consent, will the Union within three (3) days of any employee who has been assaulted while performing her or his work. Such information be submitted, in to the Union as soon as possible. The Hospital consider requests for reimbursement for damages incurred to the employee’s personal property, such as eyeglasses, ripped uniforms, personal clothing, as a result of being assaulted while performing his or her work.

Related to IN THE WORK

  • Scope of the Work The Contractor shall furnish all the materials, perform all of the Work, and do all things required by the Contract Documents.

  • Cost of the Work The sum of all allowable costs necessarily incurred and paid by Contractor in the proper performance of the Work.

  • Construction Activities In this section, please include information on the status of any construction-related factors that may affect the ability of the Project to deliver Product to the Buyer. Include information on the Project infrastructure, generating equipment, and major auxiliary equipment. Also include information on the substations, switchyards, gen-ties, telecommunications equipment or other interconnection facilities that are the direct responsibility of the Project. Overview of major construction activities Please provide a summary of the status and progress of each major construction activity for all portions of the Project, including a schedule showing expected or actual dates as applicable. Provide the name of the EPC Contractor, the date of execution of the EPC Contract, and the date of issuance of a full Notice to Proceed (or equivalent). For each major type of equipment, break out the number of each item (to be) installed and/or commissioned in each month. Recent construction activities Please describe in detail the construction activities that occurred during the previous calendar month. Expected construction activities Please list the interconnection activities that are expected to be performed during the current calendar month.

  • THE WORK The Work comprises the completed construction required by the Contract Documents and includes all labor necessary to produce such construction, and all materials and equipment incorporated or to be incorporated in such construction.

  • Project Location Enter the project location as it appears on the project advertisement.

  • The Site The site shall comprise the real estate described in Schedule-A and in respect of which the Right of Way shall be provided and granted by the Authority to the Concessionaire as a licensee under and in accordance with this Agreement (the "Site"). For the avoidance of doubt, it is hereby acknowledged and agreed that references to the Site shall be construed as references to the real estate required for the Bus Terminal as set forth in Schedule-A and includes Commercial Complex.

  • Fabrication Making up data or results and recording or reporting them.

  • Installation Where installation is required, Contractor shall be responsible for placing and installing the product in the required locations at no additional charge, unless otherwise designated on the Contract or purchase order. Contractor’s authorized product and price list shall clearly and separately identify any additional installation charges. All materials used in the installation shall be of good quality and shall be free of defects that would diminish the appearance of the product or render it structurally or operationally unsound. Installation includes the furnishing of any equipment, rigging, and materials required to install or replace the product in the proper location. Contractor shall protect the site from damage and shall repair damages or injury caused during installation by Contractor or its employees or agents. If any alteration, dismantling, excavation, etc., is required to achieve installation, the Contractor shall promptly restore the structure or site to its original condition. Contractor shall perform installation work so as to cause the least inconvenience and interference with Customers and with proper consideration of others on site. Upon completion of the installation, the location and surrounding area of work shall be left clean and in a neat and unobstructed condition, with everything in satisfactory repair and order.

  • CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.