COMMENCEMENT OF THE TERM Sample Clauses

COMMENCEMENT OF THE TERM. Subject to Section 10 above, the Term of this Lease shall commence on whichever of the following dates shall first occur: (a) The date on or after December 15, 1999 on which the Premises are "Substantially Complete" (which shall mean that (i) Landlord shall have substantially completed the work in the Premises required to be completed by Landlord as specified in Exhibit B (including the Building, the Parking Lot and all necessary access and egress thereto), exclusive of minor "punch list" items of mechanical and cosmetic adjustment that do not prevent Tenant from using or enjoying the Premises for the use intended hereunder, (ii) Landlord has furnished to Tenant a final unconditional certificate of occupancy for the Premises, and (iii) Landlord has delivered to Tenant an Environmental Assessment for the Premises (as defined in Section 29 herein) in form and substance satisfactory to Tenant; provided that, in the event Landlord shall be delayed in completing Landlord's Work by any interference with or hindrance of such work by Tenant, Tenant's contractor or any of their employees, servants or agents or by any changes in such work requested by Tenant and agreed to by Landlord ("Tenant-Caused Delays"), the Premises shall be deemed to have been Substantially Complete on the date on which Landlord would have Substantially Completed Landlord's Work had such Tenant-Caused Delay not occurred); or

COMMENCEMENT OF THE TERM which states “There will be no renewal period or extension provided in this Lease” is hereby deleted in its entirety.

COMMENCEMENT OF THE TERM. 85 32. TENANT'S WORK, ETC ................................................. 87 33.

COMMENCEMENT OF THE TERM. The Term will begin on the Delivery Date. There will be no renewal period or extension provided in this agreement.‌

COMMENCEMENT OF THE TERM. 31.01. If Landlord is unable to deliver possession of all or any portion of the demised premises for any reason, Landlord shall not be subject to any liability for failure to give possession and the validity of this Lease shall not be impaired under such circumstances, nor shall the same be construed in any way to extend the term of this Lease. If permission is given to Tenant to enter into the possession of all or any portion of the demised premises prior to the date specified as the commencement of the term of this Lease, Tenant covenants and agrees that such occupancy shall be deemed to be under all the covenants, agreements, terms, provisions and conditions of this Lease, except as to the covenant to pay rent. The provisions of this Section are intended to constitute "an express provision to the contrary" within the meaning of Section 223-a of the New York Real Property Law. 31.02. The parties hereto shall, at either party's request, within thirty (30) days after the (a) Commencement Date with respect to each portion of the demised premises constituting a portion thereof, and (b) the Rent Commencement Date, execute a written agreement confirming such date as the date of the commencement of the term of this Lease with respect to the portion of the demised premises to which it relates or the Rent Commencement Date, as the case may be. In no event shall Tenant or Landlord record this Lease or a copy hereof. However, at the request of either party hereto, each of the parties hereto shall promptly execute in recordable form and deliver to the other a memorandum of the Lease sufficient for recording. Such memorandum shall not, and shall not be deemed to, change or otherwise affect any obligations or provisions of this Lease. 107 31.03. Notwithstanding anything contained in Section 31.01 of this Lease to the contrary, in the event that Landlord (i) fails to deliver possession of a particular portion of the demised premises to Tenant in the Access Condition by the date specified for such portion of the demised premises set forth in the column marked "Access Date" on Exhibit H attached hereto and made a part hereof (the "Access Date"), (ii) fails to complete the work necessary to achieve the applicable Milestone Condition (as such term is defined in said Exhibit H) by the applicable Milestone Date, as such term is defined in said Exhibit H, or (iii) fails to Substantially Complete, as such term is defined in said Exhibit H, the Substantial Completion Work, as s...

COMMENCEMENT OF THE TERM. The Term (hereinafter defined) of this Agreement shall commence upon the performance of the first Gamma Knife procedure at the Site (the "Commencement Date"). NME shall become liable to PROVIDER for the payments referred to in Paragraph 6 hereinbelow upon the Commencement Date.

COMMENCEMENT OF THE TERM. The commencement of the Term is subject to a set of performance transfer criteria that MCC needs to meet that was presented to and approved by the Marin County Board of Supervisors on September 12, 2017, also attached on Exhibit “C” and attached hereto and by reference made a part hereof. If the Director of Health and Human Services (HHS) determines that all transfer criteria have been met by December 31, 2017, then the Term shall commence on January 1, 2018. The Director of HHS, or other County designee of the Director of HHS, has the sole authority to delay the start of this lease Term, and if so delayed, County will notify MCC via email, in-person, or via facsimile as soon as possible prior to January 1, 2018, that the transfer criteria have not been met. If the commencement of the Term is delayed beyond January 1, 2018, this Lease shall not be void or voidable, nor shall County be liable to MCC for any loss or damage resulting therefrom, nor shall the expiration date of the above Term be in any way extended, but in that event, all rent shall be abated during the period between January 1, 2018 and the actual commencement of said term. Once the transfer criteria have been met, County and MCC will sign a letter stating the actual commencement date of the Lease term.

COMMENCEMENT OF THE TERM. The Term will begin on the Effective Date. Within two

COMMENCEMENT OF THE TERM. Originals of the renewal policies or certificates therefor from the insurer evidencing the existence thereof shall be deposited with Landlord upon renewal of the applicable policies. If Landlord is provided with a certificate for a renewal policy, upon Landlord's request Tenant shall deliver a copy of the complete renewal policy to Landlord within 30 days of the expiration of the replaced policy. Any claims under any policies of insurance described in this Lease shall be adjudicated by and at the expense of the Tenant or of its insurance carrier, but shall be subject to joint control of Tenant and Landlord. The provisions of this Section 4.1 also apply to any insurance coverage required under the Development Addendum.

COMMENCEMENT OF THE TERM. (a) Notwithstanding anything herein contained to the contrary, the term of this Lease and Tenant's obligation to pay rent and occupy the Demised Premises in accordance with the terms hereof shall commence on the following date (such date being hereinafter called the "Commencement Date"): the later of: (i) the date on which Landlord delivers possession of the Premises to Tenant with Landlord's work substantially complete (unless otherwise agreed to by Tenant) or (ii) the earlier of: (a) date Tenant receives Approvals (as defined in Rider 11), or (b) sixty (60) days following the execution of this Lease. (See Rider #1 and #