Contractor Claims. In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.
Contractor Claims. The consultant shall promptly review, analyze and respond to contractor claims and costs, including delay claims and associated costs, in accordance with the general conditions of the contract for construction Exhibit H-AIA 201 General Conditions (2007 Edition) as modified by the State. (incorporated by reference, and available from RECS).
Contractor Claims. The Construction Manager shall be given copies of all notices of claims by Contractors against the District for any alleged cause. The Construction Manager, jointly with Architect, shall perform evaluation of the contents of the claim within twenty-five (25) days, and make recommendations to the District. If requested by the District, the Construction Manager shall prepare estimates based on any alleged cause of claims submitted by the Contractor(s) and shall prepare alternate estimates based on varying scenarios of the claim cause. These estimates shall be transferred to the District and shall be used in claim rulings and negotiations. If requested by the District, the Construction Manager shall analyze the claims for extension of time and prepare an impact evaluation report which reflects the actual impact to the Project Baseline Schedule. The report shall also provide a narrative including a recommendation for action to the District. If requested by the District, the Construction Manager shall negotiate claims with the Contractor(s) on behalf of the District. The Construction Manager shall make a written recommendation to the District concerning settlement or other appropriate action. Excepting those claims of which the Construction Manager is responsible, Construction Manager’s obligations pursuant to this Paragraph shall cease upon completion of the Project as defined in Article 1.4 of this Agreement.
Contractor Claims. A. If Contractor claims that any instruction, Drawing, act or omission of Owner or any representative of Owner, or any agency of government, increases costs to Contractor, requires extra time or changes the Scope of Work, Contractor shall have the right to assert a Claim for such costs or time.
Contractor Claims. The Architect shall render written decisions regarding claims, disputes or other matters in controversy between the District and the Contractor arising under or relating to the Construction Contract, including the execution or progress of Work thereunder. The Architect’s decisions shall be in accordance with any applicable time limits set forth in the Construction Contract; if no time limits are set forth, the Architect shall render decisions within a reasonable time.
Contractor Claims. 46. Agency shall, to the extent permitted by state law, indemnify, hold harmless and provide legal defense for State against all claims brought by the contractor, or others resulting from Agency’s failure to comply with the terms of this Agreement.
Contractor Claims. Contractor Claims are subject to the Section 9204 procedures provided, however, that the Section 9204 procedures are expressly subject to the Contractor’s prior full and timely compliance with requirements and procedures of the Contract Documents relating to submittal and resolution of Claims, change orders, disputes and other matters in controversy under the Contract Documents. By this reference, the Section 9204 procedures are incorporated herein.
Contractor Claims. 2.6.8 Limitations Upon Architect’s Construction Phase Services
Contractor Claims. The CM shall review claims from Contractors for additional compensation and equitable adjustment of compensation, and shall deliver a written recommendation to the COUNTY about each claim and attend dispute resolution meetings convened by the COUNTY related to each claim.
Contractor Claims. The Associate shall review claims from Contractors for additional compensation and equitable adjustment of compensation, and shall deliver a written recommendation to the University about each claim and attend any dispute resolution meetings convened by the University related to each claim.
