DELAY CLAIMS Sample Clauses

DELAY CLAIMS. Subject to the provisions of Articles 8 and 12, if the Contractor is entitled to recover additional costs incurred and/or to have an adjustment in the Contract Time as a result of events set forth in Subparagraph 6.3.1, those costs shall be recoverable and an equitable time extension granted. Subject to Paragraph 10.2, to the extent the Contractor causes delay in the completion of the Work, the Owner shall be entitled to recover its additional costs following the procedures established in Article 12.
AutoNDA by SimpleDocs
DELAY CLAIMS. 12.5.1 If the Trade Contractor is obstructed, hindered or delayed in the commencement, prosecution or completion of the Work, without fault on its part, by the Owner, the Design Consultants any other Trade Contractor employed by the Owner, or by changes in the Work, or by reason of unknown conditions (including those specified in Paragraph 9.6), adverse weather conditions, fire, lightning, earthquake, enemy action, act of God, or similar catastrophe, or by government restrictions in respect to materials or labor, or by an economic industry-wide strike or lockout beyond the Trade Contractor's reasonable control (all of which shall be deemed "Excusable Delays") then the sole and exclusive remedy of the Trade Contractor shall be to notify the Owner of such Excusable Delays and to proceed in accordance with the procedures specified in Paragraph 9.6.
DELAY CLAIMS. Consultant represents and warrants that the provisions herein contained for extension of time are fair and adequate, and that Consultant has had an opportunity to make provision for any and all delays within the contemplation of the parties. Accordingly, it is understood and agreed that Consultant shall not have or assert any claim for damages, or prosecute any suit, action, cause of action, arbitration claim or other proceeding against the Board for such damages arising from any delay or hindrance in the completion of the work called for in this Agreement due to any act or omission on the part of the Board its agents, servants and employees, or otherwise.
DELAY CLAIMS. FORWARD AIR will undertake to deliver the lading described on the Waybill under reasonable dispatch using next available equipment and shall attempt to effect delivery pursuant to the schedules and transit times as otherwise held out by FORWARD AIR. FORWARD AIR does not guarantee that delivery will be effected to meet any particular market, dispatch, exhibition, or sailing. FORWARD AIR does not accept liability for special or consequential damages or delays in delivery. Customer hereby agrees that, in any event, FORWARD AIR's maximum liability for delay shall be an amount equal to the related transportation charges incurred.
DELAY CLAIMS. Whenever the Contractor claims a delay for which the Time for Completion may be extended, the Contractor must request an extension of time within five (5) days of the start of the delay. The request must be in writing and describe in detail the cause for the delay, and, if possible, the foreseeable extent of the delay.
DELAY CLAIMS. Subject to the provisions of Articles 8 and 12, if the Contractor is entitled to recover additional costs incurred and/or to have an adjustment in the Contract Time as a result of events set forth in Subparagraph 6.3.1, those costs shall be recoverable and an equitable time extension granted. Subject to Paragraph 10.2, to the extent the Contractor causes delay in the completion of the Work, the Owner shall be entitled to recover its additional costs following the procedures established in Article 12. AGC DOCUMENT NO. 200 STANDARD FORM OF AGREEMENT AND GENERAL CONDITIONS BETWEEN OWNER AND CONTRACTOR (Where the Contract Price is a Lump Sum) 1997, The Associated General Contractors of America

Related to DELAY CLAIMS

  • Tax Claims Notwithstanding any other provision of this Agreement, the control of any claim, assertion, event or proceeding in respect of Taxes of the Company (including, but not limited to, any such claim in respect of a breach of the representations and warranties in Section 3.22 hereof or any breach or violation of or failure to fully perform any covenant, agreement, undertaking or obligation in Article VI) shall be governed exclusively by Article VI hereof.

  • Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.

  • Unpaid Claims If a claim for indemnification (following the final disposition of such action, suit or proceeding) or advancement of expenses under this Section 10.02 is not paid in full within thirty (30) days after a written claim therefor by any person described in Section 10.02(a) has been received by the Partnership, such person may file proceedings to recover the unpaid amount of such claim and, if successful in whole or in part, shall be entitled to be paid the expense of prosecuting such claim. In any such action the Partnership shall have the burden of proving that such person is not entitled to the requested indemnification or advancement of expenses under applicable Law.

  • Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties attributable to the period on or prior to the Closing except to the extent relating to the Assumed Liabilities;

  • Covered Claims Claim" means any claim, dispute or controversy between you and us that in any way arises from or relates to this Agreement, the Account, the issuance of any Card, any rewards program, any prior agreement or account. "Claim" includes disputes arising from actions or omissions prior to the date any Card was issued to you, including the advertising related to, application for or approval of the Account. "Claim" has the broadest possible meaning, and includes initial claims, counterclaims, cross-claims and third-party claims. It includes disputes based upon contract, tort, consumer rights, fraud and other intentional torts, constitution, statute, regulation, ordinance, common law and equity (including any claim for injunctive or declaratory relief). "Claim" does not include disputes about the validity, enforceability, coverage or scope of this Arbitration Provision or any part thereof (including, without limitation, the prohibition against class proceedings, private attorney general proceedings and/or multiple party proceedings described in Paragraph C.7 (the "Class Action Waiver"), the last sentence of Paragraph

  • Uncontested Claims In the event that the Indemnification ------------------ Representative does not contest a Notice of Claim (an "Uncontested Claim") in ----------------- writing within thirty (30) calendar days, as provided below in Section 2.3(b), Cambridge may deliver to the Custodian, with a copy to the Indemnification Representative, a written demand by Cambridge (a "Cambridge Demand") stating ---------------- that a Notice of Claim has been given as required in this Escrow Agreement and that no notice of contest has been received from the Indemnification Representative during the period specified in this Escrow Agreement and further setting forth the proposed Escrow Adjustments to be made in accordance with this Section 2.3(a). It is provided, however, that within thirty (30) calendar days after receipt of the Cambridge Demand, the Indemnification Representative may object in a written notice delivered to Cambridge and the Custodian to the computations or other administrative matters relating to the proposed Escrow Adjustments (but may not object to the validity or amount of the Claim previously disclosed in the Notice of Claim), whereupon neither the Custodian nor Cambridge shall make any of the Escrow Adjustments until either: (i) Cambridge and the Indemnification Representative shall have given the Custodian written notice setting forth agreed Escrow Adjustments, or (ii) the matter is resolved as provided in Sections 2.3(b) and 2.3(c). Upon satisfaction of the foregoing, the Custodian, as directed in writing by Cambridge, and Cambridge shall promptly take all steps to implement the final Escrow Adjustments.

  • Insured Claims To indemnify Indemnitee for expenses or liabilities of any type whatsoever (including, but not limited to, judgments, fines, ERISA excise taxes or penalties, and amounts paid in settlement) to the extent such expenses or liabilities have been paid directly to Indemnitee by an insurance carrier under a policy of officers’ and directors’ liability insurance maintained by the Company; or

  • Maintenance of PMI Policy; Claims With respect to each Mortgage Loan with a loan-to-value ratio in excess of 80% for which a PMI Policy is both required and has been issued, the Servicer shall, to the extent permitted by Accepted Servicing Practices, maintain or cause the Mortgagor to maintain in full force and effect a PMI Policy insuring that portion of the Mortgage Loan in excess of 75% of value, and shall cause the Mortgagor to pay the premium thereon on a timely basis, until the loan-to-value ratio of such Mortgage Loan is reduced to 80% or PMI can otherwise no longer be mandated pursuant to applicable law. In the event that such PMI Policy shall be terminated, the Servicer shall attempt to obtain from another Qualified Insurer a comparable replacement policy, with a total coverage equal to the remaining coverage of such terminated PMI Policy. The Servicer shall not take any action which would result in noncoverage under any applicable PMI Policy of any loss which, but for the actions of the Servicer would have been covered thereunder. In connection with any assumption or substitution agreement entered into or to be entered into pursuant to this Agreement, the Servicer shall promptly notify the insurer under the related PMI Policy, if any, of such assumption or substitution of liability in accordance with the terms of such PMI Policy and shall take all actions which may be required by such insurer as a condition to the continuation of coverage under such PMI Policy. If such PMI Policy is terminated as a result of such assumption or substitution of liability, the Servicer shall obtain a replacement PMI Policy as provided above. With respect to each Mortgage Loan covered by a PMI Policy or LPMI Policy, the Servicer shall take all such actions on behalf of the Owner as are necessary to service, maintain and administer the related Mortgage Loan in accordance with such Policy and to enforce the rights under such Policy. Except as expressly set forth herein, the Servicer shall have full authority on behalf of the Owner to do anything it deems appropriate or desirable in connection with the servicing, maintenance and administration of such Policy; provided that the Servicer shall not take any action to permit any modification or assumption of a Mortgage Loan covered by a LPMI or PMI Policy, or take any other action with respect to such Mortgage Loan, which would result in non-coverage under such Policy of any loss which, but for actions of the Servicer, would have been covered thereunder. The Servicer shall cooperate with the PMI insurers and shall furnish all reasonable evidence and information in the possession of the Servicer to which the Servicer has access with respect to the related Mortgage Loan. The Servicer agrees to prepare and present, on behalf of itself and the Owner, claims to the insurer under any PMI Policy or LPMI Policy in a timely fashion in accordance with the terms of such PMI Policy or LPMI Policy and, in this regard, to take such action as shall be necessary to permit recovery under any PMI Policy or LPMI Policy respecting a defaulted Mortgage Loan. Pursuant to Section 3.04, any amounts collected by the Servicer under any PMI Policy or LPMI Policy shall be deposited in the Collection Account, subject to withdrawal pursuant to Section 3.05.

  • Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.

  • Contested Claims In the event that the Indemnifying Party disputes the Claimed Amount, as soon as practicable but in no event later than ten (10) days after the receipt of the notice referenced in Section 10.2(b)(ii) hereof, the Parties will begin the process to resolve the matter in accordance with the dispute resolution provisions of Section 1.4 hereof. Upon ultimate resolution thereof, the Parties will take such actions as are reasonably necessary to comply with such agreement or instructions.

Time is Money Join Law Insider Premium to draft better contracts faster.