Selection of Architect. Landlord shall retain the architect/space planner (for purposes of this Exhibit A, the “Architect”) and the engineering consultants (for purposes of this Exhibit A, the “Engineers”) of Landlord’s choice to prepare all architectural plans for the Premises and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises. The plans and drawings to be prepared by the Architect and the Engineers shall be referred to in this Extension Work Letter as the “Plans.” Tenant shall be responsiblefor ensuring that all elements of the design of the Plans are suitable for Tenant’s use of the Premises, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility. Landlord shall cause the Architect and the Engineers to usethe Required Level of Care (defined below) to cause the Plans to comply with law; provided, however,that Tenant, not Landlord, shall be responsible for any violation of law by the Plans resulting fromTenant’s use of the Premises for other than general office purposes. As used herein, “Required Level of Care” means the level of care that reputable architects and engineers customarily use to cause drawingsand specifications to comply with law where such drawings and specifications are prepared for spaces in buildings comparable in quality to the Building. Tenant shall be responsible for ensuring that the Plans comply with law to the extent Landlord is not expressly so responsible under this Section 2.1, and neitherthe preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility. To the extent that either party (for purposes of this Exhibit A,the “Responsible Party”) is responsible under this Section 2.1 for causing the Plans to comply with law,the Responsible Party may contest any alleged violation of Law in good faith, including by seeking awaiver or deferment of compliance, asserting any defense allowed by law, and exercising any right ofappeal (provided that the other party incurs no liability as a result of such contest and that, aftercompleting such contest, the Responsible Party makes any modification to the Plans or any alteration tothe Premises that is necessary to comply with any final order or judgment).
Selection of Architect. Landlord shall retain the architect/space planner of Landlord’s choice (the “Architect”) to prepare the Architectural Drawings (defined in Section 2.5 below).
Selection of Architect. Tenant shall retain an architect/space planner (the “Architect”) approved in advance by Landlord (which approval shall not be unreasonably withheld) to prepare the Final Space Plan and Final Working Drawings as provided in Section 3.2 and 3.3, below. Landlord hereby approves of WHL Architects*Planners, Inc., as a permitted Architect hereunder. Tenant shall retain the engineering consultants or design/build subcontractors designated by Tenant and reasonably approved in advance by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building. All such plans and drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of any plans or drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters.
Selection of Architect. Tenant shall retain an architect/space planner (the "Architect") approved in advance by Landlord (which approval shall not be unreasonably withheld) to prepare the Final Space Plan and Final Working Drawings as provided in Section 3.2 and 3.3, below. Tenant shall retain the engineering consultants or design/build subcontractors designated by Tenant and reasonably approved in advance by Landlord (the "Engineers") to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises, which work is not part of the Base Building. All such plans and drawings shall comply with the drawing format and specifications reasonably determined by Landlord, and shall be subject to Landlord's reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord's review of any plans or drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord's review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters.
Selection of Architect. Tenant shall retain an architect/space planner (the “Architect”) approved in advance by Landlord (which approval shall not be unreasonably withheld) to prepare the Final Space Plan and Final Working Drawings as provided in Section 3.2 and 3.3, below. Landlord hereby approves CAC Architects or DGA Architects as the Architect and Xxxxxxxx Xxxxxxxxx as the Engineers. Tenant shall retain the engineering consultants or design/build subcontractors designated by Tenant and reasonably approved in advance by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises. All such plans and drawings shall comply with locally recognized engineering codes, applicable law and standards, and sound industry practices prevailing at the time of performance that are followed by architects or professional engineers performing similar work under similar conditions, and shall be subject to Landlord’s reasonable approval, which approval shall not be unreasonably withheld, conditioned or delayed. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of any plans or drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters.
Selection of Architect. Landlord shall retain the architect/space planner (the “Architect”) and the engineering consultants (the “Engineers”) of Landlord’s choice to prepare all architectural plans for the Suite 2000 Expansion Space and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Suite 2000 Expansion Space. The plans and drawings to be prepared by the Architect and the Engineers shall be referred to in this Work Letter as the “Plans.” Tenant shall be responsible for ensuring that all elements of the design of the Plans are suitable for Tenant’s use of the Suite 2000 Expansion Space, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility.
Selection of Architect. Tenant shall retain an architect/space planner (the “Architect”) approved in advance by Landlord (which approval shall not be unreasonably withheld) to prepare the Final Space Plan and Final Working Drawings as provided in Section 3.2 and 3.3, below. Xxxx Xxxxxxxx Xxxx Studios is hereby approved as Architect if selected by Tenant. Tenant shall retain the engineering consultants or design/build subcontractors designated by Tenant and reasonably approved in advance by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, lifesafety, and sprinkler work in the Premises, which work is not part of the Base Building. CRB is hereby approved as Tenant’s laboratory process engineer and laboratory consultant. All such plans and drawings shall comply with the reasonable industry standard drawing format and specifications, and shall be subject to Landlord’s reasonable approval. Tenant and Architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the Base Building plans, and Tenant and Architect shall be solely responsible for the same, and Landlord shall have no responsibility in connection therewith. Landlord’s review of any plans or drawings as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters.
Selection of Architect. Tenant shall retain Carrier Xxxxxxx as architect (the "ARCHITECT") to prepare the architectural plans and drawings for the Tenant Improvements in the Building in accordance with the Construction Schedule. Tenant shall have the right to replace Architect with another architect(s) from time to time at Tenant's discretion and subject to Landlord's reasonable approval. Tenant shall also retain engineering consultants (the "ENGINEERS") selected by Tenant and subject to Landlord's reasonable approval to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, lifesafety, and sprinkler work of the Tenant Improvements. The parties acknowledge that Tenant's retention of the Engineers may be done in connection with a EXHIBIT B -6- PEREGRINE SYSTEMS CORPORATE CENTER [Peregrine Systems]
Selection of Architect. Landlord has retained RE Xxxxxxx and DPS Architecture (each, individually, an “Archtect” and collectively, the “Architects”) and AHA as the MEP engineer to prepare the Construction Documents (defined in Section 2.3) for the Landlord’s Third Floor Expansion Premises TI Work. All Construction Documents shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to approval by both Landlord and Tenant as set forth herein.
Selection of Architect. Landlord shall retain the architect/space planner (the “Architect”) and the engineering consultants (the “Engineers”) of Tenant’s choice, and reasonably acceptable to, and approved by, Landlord, to prepare all architectural plans for the Premises and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises. The plans and drawings to be prepared by the Architect and the Engineers shall be referred to in this Work Letter as the “Plans.” Tenant shall be responsible for ensuring that all elements of the design of the Plans are suitable for Tenant’s use of the Premises, and neither the preparation of the Plans by the Architect or the Engineers nor Landlord’s approval of the Plans shall relieve Tenant from such responsibility. Landlord shall cause the Architect and the Engineers to use the Required Level of Care (defined below) to cause the Plans to comply with Law; provided, however, that Tenant, not Landlord, shall be responsible for any violation of Law by the Plans resulting from Tenant’s use of the Premises for other than general medical office purposes. As used herein, “Required Level of Care” means the level of care that reputable architects and engineers use, pursuant to all applicable legal and professional standards, to cause drawings and specifications to comply with Law where such drawings and specifications are prepared for spaces in buildings comparable in quality to the Building.
