Contractor Initiated Changes. If the Contractor initiates a substitution, deviation or change in the work which affects the scope of work or the expense of other trades, Contractor shall be liable for the expense thereof, and any incidental extra work created by the change to the Owner’s work.
Contractor Initiated Changes. Any other written or oral order (which, as used in this paragraph (b), includes direction, instruction, interpretation, or determination) from Princeton University that causes, or Contractor alleges to cause, a change shall be treated as a change order under this clause; provided, that the Contractor gives Princeton University written notice stating (1) the date, circumstances, and source of the order and (2) that the Contractor regards the order as a change order.
Contractor Initiated Changes. When latent or unforeseen conditions require modifications to the contract or Contractor initiates changes through a value engineering proposal, Contractor must propose said changes by submitting a request to County. Contractor shall:
Contractor Initiated Changes. Contractor may request changes in the Work by submitting a request for information to the Contracting Officer that includes the supporting documentation stated in Section 12.2.2.
Contractor Initiated Changes. The Contractor and Designer shall provide the CM with a copy of each change request. The CM shall evaluate the Contractor’s request and shall evaluate the Designer’s review comments regarding the proposed request. The CM shall review the contents of all Contractor requested changes to the contract time or price, endeavor to determine the cause of the request, and assemble and evaluate information concerning the request and if it is appropriate per the terms of the contract.
Contractor Initiated Changes. When the Contractor considers that any written instruction or interpretation of the Contract Documents issued by the Architect/Engineer constitutes a change in the Work affecting the Contract Sum and/or Time, the Contractor will so notify the A/E and ODR as soon as possible, but not later than fifteen (15) days after receipt of the instruction or interpretation, and will submit a CPE to the A/E and a copy to the ODR as soon as possible thereafter, but not later than thirty (30) days after issuance of the Contractor’s notice. This CPE will contain a proposal for an adjustment in the Contract Sum, and/or Time, as provided under Article 11. The Contractor will include with the CPE a copy of the written instruction or interpretation from the A/E or ODR, evidence of the date Contractor received the writing, and an explanation of why the Contractor believes the instruction or interpretation changes the Work and requires an adjustment to the Contract Sum.
Contractor Initiated Changes. Contractor may propose in writing changes to the Scope of Services, upon identifying a condition which may change the Scope of Services as agreed at the time of execution of this Agreement. Contractor must notify the City’s Agreement Administrator of any changed conditions upon discovery and before they are disturbed. The Public Works Director shall investigate, and if the Public Works Director determines that the conditions will materially affect costs, will issue a Change Order adjusting the compensation for such portion of the Scope of Services. If the Public Works Director determines that conditions are changed conditions and they will materially affect performance time, the Contractor, upon submitting a written request, will be granted an extension of time. If the Public Works Director determines that the conditions do not justify an adjustment in compensation or time, the Contractor will be notified in writing. This notice will also advise the Contractor of its obligation to notify the Public Works Director in writing if the Contractor disagrees. When and if City and Contractor agree on any such proposed change and its effect on the cost and time for performance, they shall confirm such agreement in writing as an amendment to this Agreement. Contractor may not cease work or delay progress on the original project pending negotiations over changes and must continue to diligently complete the project. Should the Contractor disagree with the decision, it may submit a written notice of potential claim to the Public Works Director before commencing the disputed work. In the event of such a dispute, the Contractor shall not be excused from any scheduled completion date provided by the Contract and shall proceed with all work to be performed under the Contract. However, the Contractor shall retain any and all rights provided by either Contract or law which pertain to the resolution of disputes and protests between the contracting parties. The Contractor’s failure to give notice of changed conditions promptly upon their discovery and before they are disturbed shall constitute a waiver of all claims in connection therewith.
Contractor Initiated Changes. 14 The Contractor cannot reduce the amount of work committed to a COA UDBE 15 without good cause. Reducing UDBE Commitment is viewed as partial UDBE 16 termination, and therefore subject to the termination procedures below.
Contractor Initiated Changes. 2 The Contractor cannot change the scope or reduce the amount of work 4 viewed as partial DBE termination, and therefore subject to the termination
Contractor Initiated Changes. 25 The Contractor cannot change the scope or reduce the amount of work 26 committed to a COA DBE without good cause. Reducing DBE Commitment is 27 viewed as partial DBE termination, and therefore subject to the termination 28 procedures below. 29
