Requested by Customer Clause Samples

POPULAR SAMPLE Copied 1 times
Requested by Customer. During the term of this Agreement, Customer may request that Contractor provide new or additional services under this Agreement or make certain changes in the Services provided under this Agreement, including, without limitation, (i) the addition of new or different functionality to the NPAC/SMS, (ii) a modification, reduction or expansion of existing functionality of the NPAC/SMS, (iii) the offering of additional support, training, consulting services or any other addition to or modification or expansion of the Services or alteration of the Specifications, or (iv) an increase or decrease in any new or additional services or changes previously requested pursuant to this Article 13 (collectively (including changes, modifications and reductions) “Additional Services”). Customer shall initiate its request for Additional Services by delivering a proposal to Contractor detailing the Additional Services being requested and any requirements to be met. Contractor may request further information or clarification, if needed by Contractor to formulate a response, and within three (3) weeks (or such longer or shorter period agreed to by the Parties) after Contractor’s receipt of Customer’s request (or, if later, Contractor’s receipt of any information or clarification requested by it), Contractor shall respond with a proposed Statement of Work, which shall be prepared and finalized in accordance with the requirements of this Article 13. Contractor shall not accept any such requests from or enter into Statements of Work with Users without Customer’s written approval. All requests for User Enhancements by any User must be made through Customer in the form of a request for Additional Services pursuant to Article 13 - Additional Services, and the requesting User shall be responsible for any charges or fees for such User Enhancement as provided in the related Statement of Work. Customer will not object to the incorporation of User Enhancements. Furthermore, all User requests for Additional Services will be forwarded by Customer to Contractor under the provisions set forth herein. As part of its response to any request from Customer for Additional Services that Customer states are intended to benefit more than one User, Contractor shall state (1) the price if paid by Users by a specified date and (2) the price if paid by Users over the remaining term of this Agreement. Customer may elect the pricing option it prefers. Customer’s election of either option shall not preclude ...
View SourceView Similar (3)
Requested by Customer. High Speed Internet:
View SourceView Similar (2)
Requested by Customer. High Speed Internet: VoIP Phone: Equipment provided by Company: BROADBAND SERVICE ORDER AND AGREEMENT SIGNATURE PAGE BY EXECUTING BELOW CUSTOMER UNDERSTANDS AND AGREES WITH ALL TERMS AND CONDITIONS CONTAINED IN THIS AGREEMENT. FURTHER, CUSTOMER UNDERSTANDS THE SERVICES REQUIRE ACTIVE ELECTRIC SERVICE AT CUSTOMER’S LOCATION AND IF AN ELECTRICAL SERVICE OUTAGE OCCURS, THE SERVICES, INCLUDING ALL VOICE SERVICES, IF ELECTED, MAY NOT FUNCTION. DATE: ACCOUNT NUMBER: CUSTOMER SIGNATURE: PRINT NAME: INSTALLER SIGNATURE: PRINT NAME:
View SourceView Similar (2)
Requested by Customer. If Customer engages a Third Party Vendor to deliver Third Party Products and Services, Customer agrees to obtain Company’s prior consent to such integration, access, receipt or provision (“Transfer”). If Customer requests a Transfer, Customer represents, warrants and agrees that: (i) Company, in its sole and absolute discretion, shall have the right to agree to such Transfer or decline to do so; (ii) Company shall have no liability, and makes no representation, with respect to such Third Party Products and Services; and (iii) installation, if any, of such Third Party Products or Services by Company shall constitute Professional Services, a condition of which shall be the execution of an Order for such Professional Services. Upon termination of Customer’s agreement with a Third Party Vendor, Customer immediately shall terminate Third Party Vendor’s access to the SaaS, Software and Hardware and notify Company of such termination. If the Third Party Products and Services result in the sharing of Customer Data with Third Party Company, Customer consents to the sharing by Company and its affiliates of Customer Data with such Third Party Vendor for the sole purpose of Third Party Vendor’s delivery of the Third Party Products and Services and represents that such sharing does not violate any agreement, law or regulation.
View Source
Requested by Customer. High Speed Internet: VoIP Phone: Equipment provided by Company: BROADBAND SERVICE ORDER AND AGREEMENT SIGNATURE PAGE BY EXECUTING BELOW CUSTOMER UNDERSTANDS AND AGREES WITH ALL TERMS AND CONDITIONS CONTAINED IN THIS AGREEMENT. FURTHER, CUSTOMER UNDERSTANDS THE SERVICES REQUIRE ACTIVE ELECTRIC SERVICE AT CUSTOMER’S LOCATION AND IF AN ELECTRICAL SERVICE OUTAGE OCCURS, THE SERVICES, INCLUDING ALL VOICE SERVICES, IF ELECTED, MAY NOT FUNCTION.
View Source
Requested by Customer. In the event the Customer requests a delay in the completion of the Implementation Services based on reasons out of the control of the Customer, the recurring fees as outlined in Exhibit B will be rescheduled in accordance to a mutually agreed project plan. Such requested delay may result in rescheduling portions or all of the remaining Implementation Services to the next available time frame as evaluated by OPEN SKIES, unless mutually agreed in writing otherwise. In the event the Customer requests a delay in the completion of the Implementation Services based on reasons within the control of Customer, the recurring fees as outlined in Exhibit B will remain effective. Such requested delay may result in rescheduling portions or all of the remaining Implementation Services to the next available time frame as evaluated by OPEN SKIES, unless mutually agreed in writing otherwise. OPEN SKIES reserves the right to apply additional installation fees as are necessary when rescheduling the Implementation Services due to Customer request if adequate notice is not provided OPEN SKIES. All fees as described in the Agreement and Exhibit B are to be applied based on the scheduled Target Dates. [Illegible] [Illegible] GOL - 1-8-2001 -------------- -------------- Customer OPEN SKIES Initials Initials EXHIBIT C OPEN SKIES CONTACTS 1. CUSTOMER CONTACTS OPEN SKIES agrees to provide contacts for the following areas. Customer should use these contacts as necessary. Customer contract to non-authorized OPEN SKIES personnel may result in Direct Consultation Fees as described in Exhibit B, Item 3. 1.1 OPEN SKIES RESPONSE CENTER CONTACT. The following number is to be utilized as described in Exhibit A, Section 1.3.1. (U.S.) TELEPHONE: (801) 947-7838 EMERGENCY: (801) 947-7855 1.2 COMMERC▇▇▇ ▇▇▇▇▇▇▇ ▇▇ECUTIVE/LIAISON. OPEN SKIE▇ ▇▇▇▇▇▇ ▇▇▇▇ the following individual is authorized to communicate with Customer on behalf of OPEN SKIES with respect to account management, project funding, performance and other commercial issues with respect to the Reservation Services: NAME: TIME FRIEND ADDRESS: 6322 SOUTH 3000 E., SALT LAKE CITY, UT 84121 TELEPHONE: (801) 947-7▇▇▇ ▇▇▇▇▇▇▇▇▇: (▇▇▇) ▇▇▇-▇▇▇▇ ▇-▇▇▇▇: TFRIEND@OPENS▇▇▇▇.▇▇▇ ▇.▇ AUTHORIZED F▇▇▇▇▇▇▇▇ ▇▇▇▇▇CT. Customer m▇▇ ▇▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇ finance department at the following telephone number or e-mail regarding payments, invoices or other financial issues: NAME: GEORGE BENEDICT PHONE: 801-947-7848 EMAIL: GBENEDICT@OPENSKIES.▇▇▇ ▇▇▇▇ ▇▇RDON EVANS...
View Source

Related to Requested by Customer

  • By Customer To the extent permitted by applicable law, Customer will defend Microsoft against any third-party claim to the extent it alleges that: (1) any Customer Data or non- Microsoft software hosted in an Online Service by Microsoft on Customer’s behalf misappropriates a trade secret or directly infringes a patent, copyright, trademark, or other proprietary right of a third party; or (2) Customer’s use of any Product or Fix, alone or in combination with anything else, violates the law or ▇▇▇▇▇ a third party.

  • Termination by Customer You may cancel your acceptance of the Agreement with XOOM at any time within three (3) business days of your enrollment authorization and receipt of this Agreement without penalty or

  • Indemnification by Customer Customer shall indemnify, defend and hold harmless MSIL and its affiliates from and against any loss, liability, damage, cost or expense (including attorneys' and accountants' fees and expenses incurred in the defense of any demands, claims or lawsuits) actually and reasonably incurred arising from any act, omission, conduct, or activity undertaken by MSIL on behalf of Customer, including, without limitation, any demands, claims or lawsuits initiated by a limited partner (or assignee thereof); provided that (i) MSIL has determined, in good faith, that the act, omission, conduct, or activity giving rise to the claim for indemnification was in the best interests of the Customer, and (ii) the act, omission, conduct or activity that was the basis for such loss, liability, damage, cost or expense was not the result of misconduct or negligence. Notwithstanding the foregoing, no indemnification of MSIL or its affiliates by Customer shall be permitted for any losses, liabilities or expenses arising from or out of any alleged violation of federal or state securities laws unless (i) there has been a successful adjudication on the merits of each count involving alleged securities law violations as to the particular indemnitee, or (ii) such claims have been dismissed with prejudice on the merits by a court of competent jurisdiction as to the particular indemnitee, or (iii) a court of competent jurisdiction approves a settlement of the claims against the particular indemnitee and finds that indemnification of the settlement and related costs should be made, provided with regard to such court approval, the indemnitee must apprise the court of the position of the SEC and the positions of the respective securities administrators of Massachusetts, Missouri, Tennessee and/or those other states and jurisdictions in which the plaintiffs claim that they were offered or sold Units, with respect to indemnification for securities laws violations before seeking court approval for indemnification. Furthermore, in any action or proceeding brought by a limited partner in the right of Customer to which MSIL or any affiliate thereof is a party defendant, any such person shall be indemnified only to the extent and subject to the conditions specified in the Delaware Revised Uniform Limited Partnership Act, as amended, and this Section 2. The Customer shall make advances to MSIL or its affiliates hereunder only if: (i) the demand, claim lawsuit or legal action relates to the performance of duties or services by such persons to Customer; (ii) such demand, claim lawsuit or legal action is not initiated by a limited partner; and (iii) such advances are repaid, with interest at the legal rate under Delaware law, if the person receiving such advance is ultimately found not to be entitled to indemnification hereunder.

  • By Client Client agrees to indemnify, defend and hold Agency, its officers, directors, employees, agents, attorneys, subsidiaries, affiliated companies, parent companies, representatives, and successors and assigns, harmless from and against all Losses to the extent such Losses arise out of or are primarily related to (i) the negligent or wrongful acts, errors, or omissions of Client or its employees, agents affiliates, assigns or any creditor or prior account holder, or the employees or agents of any of them, in connection with this Agreement, including but not limited to errors or omissions in connection with information furnished by Client to Agency concerning a Referred Account, or (ii) any collection effort by Client or any other collection agency as to a Referred Account.