Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
Initial Improvements (i) Tenant, following the delivery of the Premises by Landlord and the full and final execution and delivery of the Lease to which this Exhibit C is attached shall have the right to perform alterations and improvements in the Premises (the “Initial Improvements”). Notwithstanding the foregoing, Tenant and its contractors shall not have the right to perform the Initial Improvements in the Premises unless and until Tenant has complied with all of the terms and conditions of Article 9 of the Lease, including, without limitation, approval by Landlord of the final plans for the Initial Improvements and the contractors to be retained by Tenant to perform such Initial Improvements. Landlord hereby approves the conceptual plans for the Initial Improvements as shown on Schedule C-1 attached hereto (the “Conceptual Plans”), and Landlord may not unreasonably withhold, delay, or condition its approval to the Initial Improvements shown on any subsequently delivered plans and specifications with respect to elements of the Initial Improvements shown on the Conceptual Plans. To the extent Landlord objects to any plans or specifications for the Initial Improvements, it shall provide a reasonably detailed writing identifying the reasons for its objection. Landlord shall promptly provide all information, plans, and specifications with respect to the Building within Landlord’s possession or control (it being agreed that Landlord shall have no obligation to generate any new materials or summaries for the benefit of Tenant) which Tenant reasonably requests in connection with the design and construction of the Initial Improvements. Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Landlord’s approval of the contractors to perform the Initial Improvements shall not be unreasonably withheld. The parties agree that Landlord’s approval of the general contractor to perform the Initial Improvements shall not be considered to be unreasonably withheld if any such general contractor (i) does not have trade references reasonably acceptable to Landlord, (ii) does not maintain insurance as required pursuant to the terms of this Lease, (iii) does not have the ability to be bonded for the work in an amount of no less than one hundred percent (100%) of the total estimated cost of the Initial Improvements, or (iv) is not licensed as a contractor in the state/municipality in which the Premises is located. Tenant acknowledges the foregoing is not intended to be an exclusive list of the reasons why Landlord may reasonably withhold its consent to a general contractor.
Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.
Lessee Improvements Lessee shall not make or allow to be made any alterations or physical additions in or to the Leased Premises without first obtaining the prior written consent of Lessor, which consent may in the reasonable judgement of Lessor be denied. Any alterations, physical additions or improvements made by Lessee to the Leased Premises shall at once become the property of Lessor and shall be surrendered to Lessor upon the Expiration Date or sooner termination of this Lease; provided, however, that Lessor, at its option, may require Lessee to remove any physical additions and/or repair any alterations in order to restore the Leased Premises to the condition existing at the Commencement Date, all costs of removal and/or alterations to be borne by Lessee. This Section 6.02 shall not apply to moveable equipment or furniture owned by Lessee, which may be removed by Lessee at the Expiration Date or sooner termination of the term of this Lease only if Lessee is not then in default and if such equipment and furniture are not then subject to any other rights, liens and interest of Lessor.
Public Improvements Neither Seller nor the Members have any Knowledge of any existing or proposed public improvements which involve or which may result in any charge being levied or assessed against the Premises or which will or could result in the creation of any lien upon the Premises or any part thereof.
SCHOOL IMPROVEMENT The conditions which follow shall govern employee participation in any and all plans, programs, or projects included in the terms, site-based decision making, school improvement, effective schools as provided in Act 197, P.A. 1987 (Section 15.1919 (919b) MSA) or other similar plans:
Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction of the Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.
Landlord Improvements If construction to the Premises is to be performed by Landlord prior to or during Tenant's occupancy, Landlord will complete the construction of the improvements to the Premises in accordance with plans and specifications agreed to by Landlord and Tenant, which plans and specifications are made a part of this Lease by reference. Within seven (7) days of receipt of plans and specifications, Tenant shall execute a copy of the plans and specifications and, if applicable, change orders setting forth the amount of any costs to be borne by Tenant. In the event Tenant fails to execute the plans and specifications and change order within the seven (7) day period. Landlord may, at its sole option, declare this Lease cancelled or notify Tenant that the base rent shall commence on the completion date even though the improvements to be constructed by Landlord may not be complete. Any changes or modifications to the approved plans and specifications shall be made and accepted by written change order or agreement signed by Landlord and Tenant and shall constitute an amendment to this Lease.