Responsibility for Improvements to Substitution Space Sample Clauses

Responsibility for Improvements to Substitution Space. Landlord shall perform improvements to the Substitution Space in accordance with the Work Letter attached hereto as Exhibit B.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Responsibility for Improvements to Substitution Space. Tenant may perform alterations and improvements to the Substitution Space in accordance with Exhibit B attached hereto (the “Tenant Improvements”) and Tenant shall be entitled to an improvement allowance in connection with such work as more fully described in Exhibit B. Upon full execution of this Amendment by the parties hereto, Tenant shall proceed with due diligence to obtain all permits and any other required governmental approvals with respect to the Tenant Improvements so long as such permits shall remain valid until the outside date that the Substitution Space may be delivered to Tenant and Tenant may substantially complete the Tenant Improvements in accordance with this Amendment. Notwithstanding anything to the contrary set forth in the Lease, in the event that as a result of the construction of any Standard Office Improvements (defined below), any alterations, additions or improvements are necessary to comply with Laws (as defined in Section 9(a) below) (collectively, the “Compliance Modifications”) with respect to (i) the common areas of the Building, including any base Building mechanical, electrical, plumbing or fire/life safety systems (the “Common Areas”), or (ii) the Substitution Space, Tenant shall not be required to perform such Compliance Modifications except as provided below. Accordingly, except as provided below, in the event that, as a result of the construction of any Standard Office Improvements, any Compliance Modifications are required to the Common Areas or the Substitution Space to comply with Laws, Landlord, at Landlord's expense (except to the extent properly included in Operating Expenses), shall be responsible for performing such Compliance Modifications, if any. Landlord shall have the right to contest any alleged violation of Laws in good faith, including, without limitation, the right to apply for and obtain a waiver or deferment of compliance, the right to assert any and all defenses allowed by Law and the right to appeal any decisions, judgments or rulings to the fullest extent permitted by Law. Landlord, after the exhaustion of any and all rights to appeal or contest, will make any Compliance Modifications necessary to comply with the terms of any final order or judgment. Notwithstanding the foregoing, (i) Tenant, not Landlord, shall be responsible for compliance with Title 24 of the California Code of Regulations (“Title 24”) with respect to the Substitution Space and shall perform any Compliance Modifications to the...
Sample 1
Responsibility for Improvements to Substitution Space. Landlord at its sole cost and expense (subject to the terms and provisions set forth below) shall perform improvements to the Substitution Space in accordance with the work list (the "Work List") attached hereto as Schedule 1 and made a part hereof, using Building Standard methods, materials and finishes. The improvements to be performed by Landlord in accordance with Schedule 1 are hereinafter referred to as the "Landlord Work." Landlord shall enter into a direct contract for the Landlord Work with a general contractor selected by Landlord. In addition, Landlord shall have the right to select and/or approve of any subcontractors used in connection with the Landlord Work. Landlord's supervision or performance of any work for or on behalf of Tenant shall not be deemed a representation by Landlord that such work complies with applicable insurance requirements, building codes, ordinances, laws or regulations, or that the improvements constructed in accordance with Schedule 1 and any revisions thereto will be adequate for Tenant's use.
Sample 1
Responsibility for Improvements to Substitution Space. Any construction, alterations or improvements to the Substitution Space shall be performed by Tenant in accordance with Exhibit B attached hereto and made a part hereof. In any and all events, neither the Reduction Effective Date nor the Substitution Effective Date shall be postponed or delayed if the initial improvements to the Substitution Space are incomplete on the Substitution Effective Date for any reason whatsoever. Any delay in the completion of initial improvements to the Substitution Space shall not subject Landlord to any liability for any loss or damage resulting therefrom.
Sample 1
Responsibility for Improvements to Substitution Space. Tenant may perform improvements to the Substitution Space in accordance with the terms of Exhibit B attached hereto (the “Tenant Alterations”), and Tenant shall be entitled to an improvement allowance in connection with such work as more fully described in Exhibit B.
Sample 1
Responsibility for Improvements to Substitution Space. Tenant shall perform improvements to the Substitution Space in accordance with the Work Letter, and Tenant shall be entitled to an improvement allowance in connection with such work as more fully described in the Work Letter.
Sample 1
Responsibility for Improvements to Substitution Space. Provided Tenant is not in default, Tenant shall be entitled to receive an improvement allowance (the "Improvement Allowance") in an amount not to exceed Sixty-Six Thousand Seven Hundred Ninety-Nine and NO/100 Dollars ($66,799.00) (i.e., $7.81 per rentable square foot of the Substitution Space) to be applied toward the cost of performing initial construction, alteration or improvement of the Substitution Space, including but not limited to the cost of space planning, design and related architectural and engineering services. Landlord shall be entitled to deduct from the Improvement Allowance a construction management fee for Landlord's oversight of the initial improvements to the Substitution Space in an amount equal to five percent (5%) of the total cost of the initial improvements to the Substitution Space. In the event the total cost of the initial improvements to the Substitution Space exceeds the Improvement Allowance, Tenant shall pay for such excess upon demand. The entire unused balance of the Improvement Allowance, if any, shall accrue to the sole benefit of Landlord. Landlord shall pay such Improvement Allowance directly to the contractors retained to perform the construction, design or related improvement work to the Substitution Space.
Sample 1
AutoNDA by SimpleDocs
Responsibility for Improvements to Substitution Space. Landlord shall enter into a direct contract for the initial improvements to the Substitution Space with a general contractor selected by Tenant, subject to Landlord's approval which shall not be unreasonably withheld, delayed or conditioned. Tenant shall devote such time in consultation with Landlord or Landlord's architect as may be required to provide all information Landlord deems necessary in order to enable Landlord to complete, and obtain Tenant's written approval of, the plans for the initial improvements to the Substitution Space in a timely manner. All plans for the initial improvements to the Substitution Space shall be subject to Landlord's consent, which consent shall not be unreasonably withheld, delayed or conditioned. If the cost of such improvements exceeds the improvement Allowance, then prior to commencing any construction of improvements to the Substitution Space, Landlord shall submit to Tenant a written estimate setting forth the anticipated cost, including but not limited to the cost of space planning, design and related architectural and engineering services, tabor and materials, contractor's fees, and permit fees. Within a reasonable time thereafter, Tenant shall either notify Landlord in writing of its approval of the cost estimate or specify its objections thereto and any desired changes to the proposed improvements. In the event Tenant notifies Landlord of such objections and desired changes, Tenant shall work with Landlord to reach a mutually acceptable alternative cost estimate.
Sample 1

Related to Responsibility for Improvements to Substitution Space

  • Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.

  • Maintenance of Common Areas Landlord shall maintain the Common Areas in good order, condition and repair and shall operate the Project and Park, in Landlord’s reasonable discretion, as a first-class industrial/commercial real property development. Tenant shall pay, on a monthly basis, Tenant’s Pro-Rata Share (as determined below) of the costs specified below and incurred by Landlord for the operation and maintenance of the Common Areas in the manner stated in Section 4.05(e). Common Area costs include, but are not limited to, costs and expenses for the following: the emergency generator gardening and landscaping; utilities, water, storm water and sanitary sewage charges; maintenance of signs (other than tenants’ signs); premiums for liability, property damage, fire and other types of casualty insurance on the Common Areas and all Common Area improvements; all Real Property Taxes levied on or attributable to the Common Areas and all Common Area improvements; all personal property taxes levied on or attributable to personal property used in connection with the Common Areas; straight-line depreciation on personal property owned by Landlord which is consumed or used in the operation or maintenance of the Common Areas; rental or lease payments paid by Landlord for rented or leased personal property used in the operation or maintenance of the Common Areas; fees for required licenses and permits; repairing, resurfacing and repaying, striping or restriping, maintaining, painting, lighting, cleaning, refuse removal, security and similar items; sales taxes; business and occupations taxes; and a reasonable fee to Landlord for Landlord’s supervision of the Common Areas and Project management (not to exceed three percent (3%) of the Base Rents of the Project for the calendar year). Landlord may cause any or all of such services to be provided by third parties and the cost of such services shall be included in Common Area costs. Common Area costs shall not include depreciation of real property which forms part of the Common Areas. The parties acknowledge and agree that the costs for maintaining the emergency generator shall be divided pro-rata among the four buildings to which it is connected.

  • REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.

  • TENANT’S MAINTENANCE AND REPAIR Tenant at its sole expense shall comply with all applicable laws and governmental regulations governing the Premises and make all repairs necessary to keep the Premises in the condition as existed on the Commencement Date (or on any later date that the improvements may have been installed), excepting ordinary wear and tear, including without limitation the electrical and mechanical systems, any air conditioning, ventilating or heating equipment which serves the Premises, all walls, glass, windows, doors, door closures, hardware, fixtures, electrical, plumbing, fire extinguisher equipment and other equipment. Any damage or deterioration of the Premises shall not be deemed ordinary wear and tear if the same could have been prevented by good maintenance practices by Tenant. As part of its maintenance obligations hereunder, Tenant shall, at Landlord’s request, provide Landlord with copies of all maintenance schedules, reports and notices prepared by, for or on behalf of Tenant. Tenant shall obtain preventive maintenance contracts from a licensed heating and air conditioning contractor to provide for regular inspection and maintenance of the heating, ventilating and air conditioning systems servicing the Premises, all subject to Landlord’s approval. All repairs shall be at least equal in quality to the original work, shall be made only by a licensed contractor approved in writing in advance by Landlord (which approval shall not be unreasonably withheld), and shall be made only at the time or times approved by Landlord. Any contractor utilized by Tenant shall be subject to Landlord’s standard requirements for contractors, as modified from time to time. Landlord shall have the right at all times (upon at least 24 hours’ prior notice) to inspect Tenant’s maintenance of all equipment (including without limitation air conditioning, ventilating and heating equipment), and may impose reasonable restrictions and requirements with respect to repairs, as provided in Section 7.3, and the provisions of Section 7.4 shall apply to all repairs. Alternatively, Landlord may elect to make any repair or maintenance required hereunder on behalf of Tenant and at Tenant’s expense, and Tenant shall promptly reimburse Landlord for all costs incurred upon submission of an invoice. Notwithstanding anything to the contrary contained in this Section 7.1, in the event Tenant’s obligation for compliance with all applicable laws and governmental regulations, or making repairs, results in a capital improvement on Tenant’s part (or Tenant’s being obligated to reimburse Landlord for a capital improvement), Tenant shall only be responsible for the amortized cost of such capital improvement (amortized at a market cost of funds as reasonably determined by Landlord) over the useful life of such improvements during the Term (except in the event obligation for any such capital improvement is required due to Tenant’s particular use of the Premises, in which case Tenant shall be fully responsible for the entire cost and installation of such capital improvement).

  • Surrender of Premises Ownership and Removal of Trade Fixtures 23.1 No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such subtenants or subtenancies.

  • Access to Premises and Records Between the date of this Agreement ------------------------------ and the Closing Date, Seller will give Buyer and its counsel, accountants and other representatives full access during normal business hours upon reasonable notice to all the premises and books and records of the Business and to all the Assets and to the System personnel and will furnish to Buyer and such representatives all such documents, financial information, and other information regarding the Business and the Assets as Buyer from time to time reasonably may request; provided that no such investigation will affect or limit the scope of any of Seller's representations, warranties, covenants and indemnities in this Agreement or any Transaction Document or limit liability for any breach of any of the foregoing.

  • Access to Premises Landlord, its agents, servants, or employees may enter the Premises at reasonable times with reasonable advance notice to Tenant (or an authorized employee of Tenant at the Premises), and at any time, upon reasonable notice to Tenant under the circumstances, in an emergency, to do the following: inspect the Premises; comply with all laws, orders, ordinances and requirements of any governmental unit or authority for which Landlord may be responsible under this Lease, if any; show the Premises to prospective lenders or purchasers and, during the ninety (90) days immediately prior to the expiration of this Lease if Tenant declines to renew for an additional term in accordance with the provisions of this Lease, to prospective tenants, but only if all such showings are accompanied by a representative of Tenant if so requested by Tenant; or post (on the Development, but not within or at the entrance of the Premises) for sale or for lease signs; provided; however, that all such entries shall be completed promptly in a good workmanlike manner so as to cause the least practical interference to Tenant’s business and Tenant’s use of the Premises. In all events, Landlord shall use commercially reasonable efforts to minimize interference with the Premises and Tenant’s business operations thereon. If Landlord’s entry materially and substantially interferes with the conduct of Tenant’s business and/or cause damage to Tenant’s property (and the entry is not needed because of Tenant’s default, negligence or willful misconduct), then in such event the rent and any sums due and payable as additional rents, shall xxxxx in proportion to the extent of the interference and Landlord shall be liable for any damage to Tenant’s property.

  • Removal of Improvements Except as otherwise expressly agreed to by Lessor and Lessee, Lessee shall have the right to remove all Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property installed by Lessee from the Premises upon the termination or expiration of this Lease, but in no event later than the date that is 120 days following the expiration or termination of this Lease (the “Removal Date”) and Lessor shall provide Lessee with access to the Premises at reasonable times until expiration of the Removal Date for the purpose of removing such items. Lessee shall provide Lessor with written notice of its election to remove the Tank Farm Assets and other improvements, fixtures, equipment, materials, supplies and personal property from the Premises at least 60 days prior to the expiration of the Lease. If Lessee elects to remove the Tank Farm Assets and Improvements from the Premises after such removal Lessee shall restore any damage to the Premises and clean the Premises so as to eliminate therefrom any accumulation (other than any de minimis and non-hazardous accumulation) of foreign substances, materials, or debris, in addition to any Environmental Cleanup that may be required under Article 10. Lessee shall pay Lessor pro rata Rent (based on the amount of Rent applicable during the last month prior to the termination or expiration) through the date of Lessee’s complete removal of all such items. During the period of such removal and clean-up, all terms and conditions of this Lease, including, the indemnity and insurance provisions shall continue in full force and effect. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date, and provided that such facilities are in good working condition at the expiration of the Term (ordinary wear and tear excepted) then, such Tank Farm Assets and Improvements shall be deemed permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee. If Lessee elects not to remove all of the Tank Farm Assets and Improvements from the Premises on or before the Removal Date and such facilities are not in good working condition at the expiration of the term (ordinary wear and tear excepted), or Lessee fails to so remove any or all of the Tank Farm Assets and Improvements from the Premises before the Removal Date, then, in addition to all rights and remedies available at law or in equity, without any prior notice, Lessor may (but shall be under no obligation), at Lessor’s option, deem such Tank Farm Assets and Improvements to be permanently abandoned to Lessor’s sole ownership, and Lessor may remove and dispose of such facilities in any manner which Lessor may deem appropriate, without any liability whatsoever to Lessee, and Lessee shall reimburse Lessor for all costs of such removal and disposal upon demand from Lessor. If requested by Lessor, Lessee shall execute any and all documents necessary to evidence that title to the Tank Farm Assets and Improvements that Lessee does not remove by the Removal Date is in Lessor and to extinguish and remove any cloud or potential cloud on the title to the Premises and/or such facilities created by Lessee.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.

  • MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot]. [Insert any other clauses in relation to maintenance of project, infrastructure and equipment]

Time is Money Join Law Insider Premium to draft better contracts faster.