Recovery and Recovery Schedule Sample Clauses

Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the Monthly Progress Report show that any activity on the critical path is forty-five (45) or more Days behind schedule, or should Contractor fail to provide a Monthly Progress Report in compliance with the requirements of this Agreement and Owner reasonably determines that any activity on the critical path is forty-five (45) or more Days behind schedule and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule (“Recovery Schedule”). Within ten (10) Business Days after the determination by Owner of the requirement for a Recovery Schedule, Contractor shall prepare the Recovery Schedule and submit it to Owner for its review. The Recovery Schedule shall (i) represent Contractor’s best judgment as to how it shall regain compliance with the CPM Schedule, (ii) be prepared in accordance with GECP, (iii) have a level of detail sufficient for Contractor to direct, manage and perform the Work, and (iv) have a maximum duration of sixty (60) Days unless recovery cannot be reasonably achieved in such time, in which case the duration of the Recovery Schedule shall be for that period of time reasonably necessary to regain compliance with the CPM Schedule. Contractor shall address all comments received from Owner during Owner’s review of the Recovery Schedule, and Contractor shall provide a written statement describing why any of Owner’s comments or proposed changes to the Recovery Schedule were not implemented by Contractor. Any of Owner’s comments or proposed changes to the Recovery Schedule that Contractor implements should be reflected in the revised Recovery Schedule. The revised Recovery Schedule shall then be the schedule which Contractor shall use in planning, organizing, directing, coordinating, performing, and executing the Work (including all activities of Subcontractors and Sub-subcontractors) to regain compliance with the CPM Schedule. The cost of preparing and executing the Recovery Schedule shall be at Contractor’s sole cost and expense; provided, however, if the preparation of a Recovery Schedule is combined with a request by Owner for a Change Order and the cost of preparing the Change Order for such request (exclu...
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) either (a) the Monthly Updated CPM Schedule or Monthly Progress Report show that any activity on a critical path of the CPM Schedule is delayed such that Mechanical Completion or Final Completion is forecasted to occur ten (10) or more Days after the applicable Guaranteed Date or a Schedule Milestone is forecasted to occur ten (10) or more Days after the applicable Milestone Schedule Date, (b) Contractor fails to provide a Monthly Updated CPM Schedule in compliance with the requirements of this Agreement and Owner reasonably determines that any activity on a critical path is delayed such that Mechanical Completion or Final Completion is forecasted to occur ten (10) or more Days after the applicable Guaranteed Date or a Schedule Milestone is forecasted to occur ten (10) or more Days after the applicable Milestone Schedule Date or (c) Contractor fails to achieve a Schedule Milestone within ten (10) Days after the applicable Schedule Milestone Date and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, then Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule during the immediate subsequent pay period or other period selected by Owner (“Recovery Schedule”) Contractor shall do the following after written notification by Owner of the requirement for a Recovery Schedule:
Sample 1Sample 2See All (5)
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the Monthly Progress Report show that any activity on the critical path is forty-five (45) or more Days behind schedule, or should Contractor fail to provide a Monthly Progress Report in compliance with the requirements of this Agreement and Owner reasonably determines that any activity on the critical path is forty-five (45) or more Days behind schedule and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule (“Recovery Schedule”). Within ten (10) Business Days after the determination by Owner of the requirement for a Recovery Schedule, Contractor shall prepare the Recovery Schedule and submit it to Owner for its review. The Recovery Schedule shall (i)
Sample 1Sample 2Sample 3
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the Monthly Progress Report show that any activity on the critical path is forty-five (45) or more Days behind schedule, or should Contractor fail to provide a Monthly Progress Report in compliance with the requirements of this Agreement and Owner reasonably determines that any activity on the critical path is forty-five (45) or more Days behind schedule and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule (“Recovery Schedule”). Within ten (10) Business Days after the determination by Owner of the requirement for a Recovery Schedule, Contractor shall prepare the Recovery Schedule and submit it to Owner for its review. The Recovery Schedule shall (i) represent Contractor’s best judgment as to how it shall regain compliance with the CPM Schedule, (ii) be prepared in accordance with GECP, (iii) have a level of detail sufficient for Contractor to direct, manage and perform the Work, and (iv) have a maximum duration of sixty (60) Days unless recovery cannot be reasonably
Sample 1Sample 2Sample 3
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the CPM Schedule or Progress Report show that any activity on the critical path of the CPM Schedule is delayed such that Substantial Completion or Final Completion of the Work will occur fourteen (14) or more Days after the Guaranteed Required Mechanical Completion Date, Guaranteed Required Substantial Completion Date, or Guaranteed Required Final Completion Date, and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare, at Contractor’s cost, a schedule to explain and display how it intends to regain compliance with the CPM Schedule (“Recovery Schedule”). After the written notification by Owner of the requirement for a Recovery Schedule, Contractor shall:
Sample 1Sample 2
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the Monthly Progress Report show that any activity on the critical path is forty-five (45) or more Days behind schedule, or should Contractor fail to provide a Monthly Progress Report in compliance with the requirements of this Agreement and Owner reasonably determines that any activity on the critical path is forty-five (45) or more Days behind schedule and (ii) Contractor or any of its Subcontractors or Sub-subcontractors are in Owner’s reasonable judgment responsible for such delay, Owner may, in addition to any other remedies that it may have under this Agreement, require that Contractor prepare a schedule to explain and display how it intends to regain compliance
Sample 1
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, should (i) the Monthly Updated CPM Schedule shows (or if Contractor has not provided the Monthly Updated CPM Schedule and Owner reasonably determines) that any activity on the critical path of the Monthly Updated CPM Schedule is delayed such that achievement of a Key Date (including a Guaranteed Date) is forecasted to occur thirty (30) or more Days after the applicable Key Date, or (ii) Contractor fails to achieve a Key Date within thirty (30) Days after the applicable Key Date, then Owner may, in addition to any other remedies that it may have under this Agreement, require that, as soon as reasonably possible, Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule to the extent required to achieve Substantial Completion of the applicable Train prior to the Guaranteed Substantial Completion Date for such Train (“Recovery Schedule”). Contractor shall do the following after written notification by Owner of the requirement for a Recovery Schedule:
Sample 1
AutoNDA by SimpleDocs
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, (i) should the Monthly Progress Report show that any activity on the critical path is forty-five (45) or more Days behind schedule, or should Contractor fail to provide a Monthly
Sample 1
Recovery and Recovery Schedule. If, at any time during the prosecution of the Work, should (i) the Monthly Updated CPM Schedule shows (or if Contractor has not provided the Monthly Updated CPM Schedule and Owner reasonably determines) that any activity on the critical path of the Monthly Updated CPM Schedule is delayed such that achievement of a Key Date (including a Guaranteed Date) is forecasted to occur thirty (30) or more Days after the applicable Key Date, or (ii) Contractor fails to achieve a Key Date within thirty (30) Days after the applicable Key Date, then Owner may, in addition to any other remedies that it may have under this Agreement, require that, as soon as reasonably possible, Contractor prepare a schedule to explain and display how it intends to regain compliance with the CPM Schedule to the extent required to achieve Substantial Completion prior to the Guaranteed Substantial Completion Date (“Recovery Schedule”). Contractor shall do the following after written notification by Owner of the requirement for a Recovery Schedule:
Sample 1

Related to Recovery and Recovery Schedule

  • Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.

  • Cost Recovery Fee You understand and agree that in order for XOOM to offer and fulfill its fixed rate obligation to you, it has to purchase electricity in advance of usage in amounts needed to cover the full term of this Agreement. If you cancel this Agreement early, you will be responsible for paying the cost recovery fee (“Cost Recovery Fee”) set forth in the Contract Summary, which is intended not as a penalty, but simply to offset the cost of selling the unused portion of your electricity to others and estimated lost revenue that XOOM may incur from such a sale, if any, and related expenses. It will take time for your local utility company to cancel your XOOM account. During that time you agree to pay for the electricity you consume that is supplied by XOOM.

  • Cost Recovery for RSTEP Requests by Registry Operator for the approval of Additional Services pursuant to Section 2.1 may be referred by ICANN to the Registry Services Technical Evaluation Panel (“RSTEP”) pursuant to that process at xxxx://xxx.xxxxx.xxx/en/registries/rsep/. In the event that such requests are referred to RSTEP, Registry Operator shall remit to ICANN the invoiced cost of the RSTEP review within fourteen (14) calendar days of receipt of a copy of the RSTEP invoice from ICANN, unless ICANN determines, in its sole and absolute discretion, to pay all or any portion of the invoiced cost of such RSTEP review.

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price Decreases Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Maintenance of the Primary Insurance Policies; Collections Thereunder (a) The Master Servicer shall not take, or permit any Subservicer to take, any action which would result in non-coverage under any applicable Primary Insurance Policy of any loss which, but for the actions of the Master Servicer or Subservicer, would have been covered thereunder. To the extent coverage is available, the Master Servicer shall keep or cause to be kept in full force and effect each such Primary Insurance Policy until the principal balance of the related Mortgage Loan secured by a Mortgaged Property is reduced to 80% or less of the Appraised Value in the case of such a Mortgage Loan having a Loan-to-Value Ratio at origination in excess of 80%, provided that such Primary Insurance Policy was in place as of the Cut-off Date and the Company had knowledge of such Primary Insurance Policy. The Master Servicer shall be entitled to cancel or permit the discontinuation of any Primary Insurance Policy as to any Mortgage Loan, if the Stated Principal Balance of the Mortgage Loan is reduced below an amount equal to 80% of the appraised value of the related Mortgaged Property as determined in any appraisal thereof after the Closing Date, or if the Loan-to-Value Ratio is reduced below 80% as a result of principal payments on the Mortgage Loan after the Closing Date. In the event that the Company gains knowledge that as of the Closing Date, a Mortgage Loan had a Loan-to-Value Ratio at origination in excess of 80% and is not the subject of a Primary Insurance Policy (and was not included in any exception to the representation in Section 2.03(b)(iv)) and that such Mortgage Loan has a current Loan-to-Value Ratio in excess of 80% then the Master Servicer shall use its reasonable efforts to obtain and maintain a Primary Insurance Policy to the extent that such a policy is obtainable at a reasonable price. The Master Servicer shall not cancel or refuse to renew any such Primary Insurance Policy applicable to a Nonsubserviced Mortgage Loan, or consent to any Subservicer canceling or refusing to renew any such Primary Insurance Policy applicable to a Mortgage Loan subserviced by it, that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for such canceled or non-renewed policy is maintained with an insurer whose claims-paying ability is acceptable to each Rating Agency for mortgage pass-through certificates having a rating equal to or better than the lower of the then-current rating or the rating assigned to the Certificates as of the Closing Date by such Rating Agency.

  • Cost Recovery The Parties acknowledge that the price for energy as described in Exhibit A includes the Consultant Commission described in Exhibit A to cover the cost of developing, implementing and operating the Aggregation. The Competitive Supplier agrees to include this cost adder in the Price for energy, and to make the monthly commission payments on behalf of Participating Consumers, in the manner described in Exhibit A, and acknowledges this obligation as a material obligation of this Agreement.

  • Additional Provisions Respecting Insurance (a) All insurance required by this Tenant Agency Compliance Agreement shall be procured and maintained in financially sound and generally recognized responsible insurance companies authorized to write such insurance in the State and selected by the entity required to procure the same. The company issuing the policies required by Section 2.1(a) hereof shall be rated “A” or better by A.M. Best Co., Inc. in Best’s Key Rating Guide. Such insurance may be written with deductible amounts comparable to those on similar policies carried by other companies engaged in businesses similar in size, character and other respects to those in which the procuring entity is engaged. All policies of insurance required by Section 2.1 hereof shall provide for at least thirty (30) days prior written notice to the Agency of the restriction, cancellation or modification thereof. The policy evidencing the insurance required by Section 2.1(c) hereof shall name the Agency as an additional insured. All policies evidencing the insurance required by Section 2.1 (d)(ii) and (iv) shall name the Agency and the Tenant as additional insureds.

  • Regulatory and Special Allocations Notwithstanding the provisions of Section 5.01:

  • Settlement and Recovery of Funding for Prior Years (a) The HSP acknowledges that settlement and recovery of Funding can occur up to 7 years after the provision of Funding.

  • PROCUREMENT OF RECOVERED MATERIAL H-GAC and the Respondent must comply with section 6002 of the Solid Waste Disposal Act, as amended by the Resource Conservation and Recovery Act. The requirements of Section 6002 include: (1) procuring only items designated in guidelines of the Environmental Protection Agency (EPA) at 40 CFR part 247 that contain the highest percentage of recovered materials practicable, consistent with maintaining a satisfactory level of competition, where the purchase price of the item exceeds $10,000 or the value of the quantity acquired during the preceding fiscal year exceeded $10,000; (2) procuring solid waste management services in a manner that maximizes energy and resource recovery; and (3) establishing an affirmative procurement program for procurement of recovered materials identified in the EPA guidelines. Pursuant to the Federal Rule above, as required by the Resource Conservation and Recovery Act of 1976 (42 U.S.C. § 6962(c)(3)(A)(i)), Respondent certifies that the percentage of recovered materials content for EPA-designated items to be delivered or used in the performance of the Contract will be at least the amount required by the applicable contract specifications or other contractual requirements. A RTICLE 40: XXXXXXXX “ANTI-KICKBACK” ACT Contractor shall comply with 18 U.S.C. § 874, 40 U.S.C. § 3145, and the requirements of 29 C.F.R. pt. 3 as may be applicable, which are incorporated by reference into the contract. The contractor or subcontractor shall insert in any subcontracts the clause above and such other clauses as appropriate agency instructions require, and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall be responsible for the compliance by any subcontractor or lower tier subcontractor with all of these contract clauses. A breach of the contract clauses above may be grounds for termination of the Contract, and for debarment as a contractor and subcontractor as provided in 29 C.F.R. § 5.12.

Time is Money Join Law Insider Premium to draft better contracts faster.