Prosecution of the Work. The time of beginning, rate of progress, and time of completion of the work are the essence of this Agreement. The Artist must do the work at such time, and in such order, as will result in successful completion of the Project during the time specified in the Agreement and the approved construction schedule. The Artist must furnish tools and equipment for the Project in sufficient quantity and of a capacity and type that will safely perform the work specified without delay in the progress of the work.
Prosecution of the Work. 1. All construction activities shall be conducted so as to avoid disturbance of other tenants. Landlord may require that all demolition and other categories of work that may inconvenience other tenants or disturb Building operations be scheduled and performed before or after Normal Building Operating Hours (at times determined by Landlord), and Tenant shall provide the Building manager with at least two Business Days’ notice prior to proceeding with any such work.
Prosecution of the Work. The Design/Builder shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Schedule. If the rate of progress is such that the total amount of Work and/or the degree of completion of the Project accomplished by the Design/Builder within any time period required by the Schedule is less than the amount therein specified, the Design/Builder shall so notify the Owner. If the delay is an Unexcused Delay, the Design/Builder shall prepare a recovery schedule for the Owner's review and approval, showing how the Design/Builder will compensate for the delays and achieve Substantial Completion by the date shown on the Schedule. If the Design/Builder is unable to demonstrate how it will overcome Unexcused Delays, the Owner may order the Design/Builder to employ such extraordinary measures as are necessary to bring the Work into conformity with the Substantial Completion Date set forth therein, the costs of which shall be paid as Cost of the Work. If the delay is an Excusable Delay, the Owner shall either (a) authorize an equitable extension in the Schedule to account for such delay, and equitably adjust the GMP on account of such delay, to the extent permitted by Article 6; or (b) request that the Design/Builder prepare a recovery schedule showing how (if possible) the Design/Builder can achieve Substantial Completion by the date shown on the Schedule, and equitably adjust the GMP in accordance with the Change Order provisions of this Agreement on account of any extraordinary activities required of the Design/Builder on account of such recovery schedule.
Prosecution of the Work. 2.2.1 The Contractor shall proceed with the Work and every part and detail thereof in a prompt and diligent manner and shall do the several parts thereof at such times and in such order as the Owner’s Representative and the Owner may direct and in accordance with Project Schedule.
Prosecution of the Work. The Contractor agrees to prosecute all work under this Contract continuously and diligently and to meet all milestones contained in the Contract. The Contractor further agrees that no charges or claims for damages shall be made by it for any delays or hindrances from any cause whatsoever during the progress of any portion of the work specified in this Contract. Time extensions will be granted only for excusable delays that arise from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including but not restricted to, acts of God, acts of the public enemy, acts of the State in either its sovereign or contractual capacity, acts of another Contractor in the performance of a contract with the State, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, or delays of subcontractors or suppliers arising from unforeseeable causes beyond the control and without the fault or negligence of either the Contractor or the subcontractors or suppliers.
Prosecution of the Work. The Construction Manager shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Master Schedule. If the delay is an Inexcusable Delay, as defined below, the Construction Manager shall prepare a recovery schedule for the City’s review and approval, showing how the Construction Manager will compensate for the delays and achieve Substantial Completion by the date shown on the Master Schedule. If the Construction Manager is unable to demonstrate how it will overcome Inexcusable Delays, the City may order the Construction Manager to employ such extraordinary measures as are necessary to bring the Work into conformity with the date of Substantial Completion set forth therein, the costs of which shall be included as part of the Cost of the Work. If the delay is an Excusable Delay, as defined below, the City shall either (A) authorize an equitable extension in the Master Schedule to account for such delay, and equitably adjust the GMP on account of such delay or (B) request that the Construction Manager prepare a recovery schedule showing how (if possible) the Construction Manager can achieve Substantial Completion by the date shown on the Master Schedule, and equitably adjust the applicable GMP in accordance with the Change Order provisions of this Agreement related to any extraordinary activities required of the Construction Manager on account of such recovery schedule.
Prosecution of the Work. The Job Order Contractor shall prosecute the Work so that the portion of the Work completed at any point in time shall be not less than as required by the Job Order Schedule. If the delay is an Inexcusable Delay, as defined below, the Job Order Contractor shall prepare a recovery schedule for the City’s review and approval, showing how the Job Order Contractor will compensate for the delays and achieve Substantial Completion by the date shown on the Job Order Schedule. If the Job Order Contractor is unable to demonstrate how it will overcome Inexcusable Delays, the City may order the Job Order Contractor to employ such extraordinary measures as are necessary to bring the Work into conformity with the date of Substantial Completion set forth therein, the costs of which shall be included as part of the Cost of the Work. If the delay is an Excusable Delay, as defined below, the City shall either:
Prosecution of the Work. 1. All construction activities shall be conducted so as to avoid disturbance of other tenants of the Building without their consent. If Landlord determines in good faith that any demolition or other work of Tenant (performed in an area that is proximate to Suite 600 or any other suite occupied by another tenant) is likely to disturb or interfere with other tenants of the Building, Landlord may require that such work be scheduled and performed outside of Normal Building Operating Hours, and Tenant shall provide the Building manager with at least two Business Days’ notice prior to proceeding with any such work, provided that Landlord shall not require such work to be performed outside of Normal Building Operating Hours if Tenant shall have made arrangements with the affected tenant(s) to perform such work at times acceptable to such other tenant(s).
Prosecution of the Work. The Contractor shall begin Work on the Project in accordance with the project completion schedule within ten (10) days after written notification of the acceptance by the County of the executed documents, unless otherwise directed by the Engineer. The Contractor shall notify the Engineer at least forty-eight (48) hours in advance of the time he intends to start. Under this Contract, time is of the essence; hence the Contractor has a duty to complete the Work within the time limits set forth in the Contract. If, in the judgment of the Engineer, the Contractor is not proceeding as rapidly as is provided in the project completion schedule, the Engineer may direct the use of extra men and equipment, extra shifts or seven-day-a week operations to insure completion of the Work or any section of the Work within dates specified in the Contract. Any of the above requirements directed by the Engineer shall be performed by the Contractor at no additional cost to the County. The Contractor's failure to comply with this Subsection shall be cause for termination of' the Contract in accordance with Subsection 107.09 titled, “Termination of Contract.”
Prosecution of the Work. (a) All Work shall be done under the general supervision and direction of Owner; Contractor shall at all times furnish adequate, qualified job site supervision to direct the Work. The decision of Owner about the meaning the Contract Documents shall be final. Notwithstanding the foregoing, Contractor represents and warrants that it is technically, financially, and legally ready, willing, and able to perform the Work hereunder and that it is familiar with and knowledgeable about the applicable laws and regulations, and government agency policy documents to the extent necessary to carry out its duties in a professional, complete, and compliant manner. Contractor further represents and warrants that Work performed by or delivered through Contractor shall be in accordance with the generally accepted standards of the profession at the time of performance and shall conform to the provisions of this Contract. Contractor shall replace any part of the Work that fails to comply with this Contract.
