Landlord Caused Delays Sample Clauses

Landlord Caused Delays. The Lease Commencement Date shall occur as provided in Section 2.1 of this Lease and Section 3.2 of the Summary; provided, however, that the Lease Commencement Date shall be extended on a day-for-day basis by the number of actual days of delay of the “Substantial Completion of the Improvements,” as that term is defined in Section 5.3 below, to the extent caused by a Landlord Caused Delay. As used in this Tenant Work Letter, “Landlord Caused Delay” shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to timely approve or disapprove any Construction Drawings; (ii) material and unreasonable interference by Landlord, its agents, employees or contractors with the Substantial Completion of the Improvements and which objectively preclude or delay the construction of Improvements in the Building by any person, which interference relates to access by Xxxxxx, or Xxxxxx’s Agents to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; (iii) delays due to the acts or failures to act of Landlord, its agents, employees or contractors including without limitation any such acts or failures to act with respect to payment of the Improvement Allowance; and (iv) delays due to Landlord’s non-delivery of the Premises in a condition which allows Tenant to construct the Improvements without material delays and/or any lack of reasonably sufficient access thereto to allow Tenant to construct the Improvements on a timely basis.
Sample 1Sample 2See All (12)
AutoNDA by SimpleDocs
Landlord Caused Delays. Each Lease Commencement Date shall occur as provided in Section 2.1 of this Lease, provided that each Lease Commencement Date shall be extended by the number of days of delay of the Substantial Completion of the Tenant Improvements, as that term is defined in Section 5.3, below, in the applicable portion of the Premises to the extent (i) caused by a Landlord Caused Delay, as that term is defined below, and (ii) the subject delay causes the Substantial Completion of the Tenant Improvements to occur after March 1, 2020. As used herein, the term "Landlord Caused Delay" shall mean actual delays to the extent resulting from the acts or omissions of Landlord including, but not limited to (a) material and unreasonable interference by Landlord, its agents or other Landlord Parties (except as otherwise allowed under this Tenant Work Letter) with the Substantial Completion of the Tenant Improvements which objectively precludes or delays the construction of Tenant Improvements, which interference relates to access by Tenant, or Tenant's Agents to the Building or any Critical Common Areas or service (including temporary power) during normal construction hours, or the use thereof during normal construction hours, and (b) delays due to the acts or failures to act of Landlord with respect to payment of the Tenant Improvement Allowance (except as otherwise allowed under this Tenant Work Letter).
Sample 1
Landlord Caused Delays. The Lease Commencement Date shall occur as provided in Section 2.1 of this Lease and Section 3.2 of the Summary, provided that the Lease Commencement Date shall be extended (but
Sample 1
Landlord Caused Delays. To the extent there shall be a delay or there are delays in the “Substantial Completion of the Tenant Improvements,” as that term is defined in Section 7.3, below, due to a “Landlord Caused Delay,” then the Commencement Date shall be extended for each “Landlord Delay Day,” as that term is defined in Section 7.2, below. As used in this Exhibit B and subject to the qualifications and conditions set out in Section 7.2 below, the term “Landlord Caused Delay” shall mean actual delays to the extent resulting from: (i) any material and unreasonable interference by Landlord, its agents, employees or contractors with the Substantial Completion of the Tenant Improvements and which objectively preclude or delay the construction of tenant improvements in the Building by any person, which interference relates to access by Tenant, or the Contractor to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; or (ii) Landlord’s failure to pay any sums out of the Allowance which are properly due and payable under the terms of Section 5.2 of this Exhibit B and which do not relate to any request for payment which is being contested in good faith by Landlord.
Sample 1
Landlord Caused Delays. If Tenant's applications for Government Approvals are denied or delayed due to any violations or other contingencies caused by the acts or omissions of Landlord or its employee, agents or other tenants, the obligation to pay rent either under this Lease or the 1993 Lease shall be abated pending Landlord's removal of such violations or contingencies. If Landlord elects not to remove such violations or contingencies, Landlord or Tenant may cancel this Lease in accordance with Article 17, and the 1993 Lease will continue in accordance with its terms, subject to the amended notification and term provisions as set forth herein.
Sample 1

Related to Landlord Caused Delays

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

  • Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.

  • Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Tenant’s Termination Right If the part of the Buildings or the Real Property so acquired or condemned contains a substantial part of the total area of the portion of the Premises located in such Building immediately prior to such acquisition or condemnation, or if, by reason of such acquisition or condemnation, Tenant no longer has reasonable means of access to the Premises, Tenant may terminate this Lease as to such portion of the Premises by notice to Landlord given within 60 days following the date upon which Tenant received notice of such acquisition or condemnation; provided, however, that if the portion of the Premises so affected shall be the Music Hall, then Tenant’s right of termination shall apply to the whole of the Premises. Furthermore, if by virtue of the nature of the space in the Music Hall which is acquired or condemned, the space remaining in the Music Hall after giving effect to such acquisition or condemnation cannot economically be used for its intended purpose, following the date upon which Tenant received notice of such acquisition or condemnation, Tenant may terminate this Lease by notice to Landlord. If Tenant so notifies Landlord, this Lease shall terminate and the Term shall end and expire upon the date set forth in the notice as to the portion of the Premises covered thereby, which date shall not be more than 30 days following the giving of such notice. If a part of the Premises shall be so acquired or condemned and this Lease and the Term shall not be terminated in accordance with this Section, Landlord, at Landlord’s expense but without requiring Landlord to spend more than it collects as an award, shall, subject to the provisions of any Mortgage or Superior Lease, restore such portion of the Premises not so acquired or condemned to a self-contained unit substantially equivalent (with respect to character, quality, appearance and services) to that which existed immediately prior to such acquisition or condemnation, to the extent commercially practicable to do so, in which case Tenant shall be obligated to restore Tenant’s Property relating to such portion of the Premises to the condition which existed immediately prior to such acquisition or condemnation.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

Time is Money Join Law Insider Premium to draft better contracts faster.