Landlord Caused Delay Sample Clauses

Landlord Caused Delay. As used herein, "Landlord Caused Delay" shall mean actual delays in the substantial completion of the Expansion Premises to the extent resulting from interference (when judged in accordance with industry custom and practice) with Tenant's construction of the Expansion Tenant Improvements in the Expansion Premises to the extent caused by (i) Landlord's failure to timely approve or disapprove any matter requiring Landlord's pertaining to the Expansion Tenant Improvements within the time periods set forth above or if not specified, within a reasonable period of time; (iii) Landlord's failure to timely disburse the Expansion Tenant Improvement Allowance; (ii) material and unreasonable interference by Landlord with substantial completion of the Expansion Premises if such interference (A) objectively precludes or delays the construction of tenant improvements in the 100 Building or any portion thereof, and (B) relates to access by Tenant to the Expansion Premises or any of the 100 Building's facilities (including loading docks and freight elevators) or services and utilities (including temporary power and parking areas as provided herein) during normal construction hours, or the use thereof during normal construction hours; or (iii) the negligence or willful misconduct of Landlord or the Landlord Parties pertaining to the Expansion Premises. If Tenant contends that a Landlord Caused Delay has occurred, Tenant shall notify Landlord in writing of the event which constitutes such Landlord Caused Delay. Tenant will additionally use reasonable efforts to mitigate the effects of any Landlord Caused Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. In addition, Tenant shall endeavor to provide notice to Landlord when Tenant becomes aware of any expected or potential Landlord Caused Delays prior to any such delay actually occurring, in order to allow Landlord to attempt to mitigate such potential delay. If such actions, inaction or circumstance described in the notice (the "Landlord Delay Notice") are not cured by Landlord within one (1) business day of Landlord’s receipt of the Landlord Delay Notice and if such action, inaction or circumstance otherwise qualify as a Landlord Caused Delay, then a Landlord Caused Delay shall be deemed to have occurred commencing as of the date of Landlord’s receipt of the...
Sample 1See All (6)
AutoNDA by SimpleDocs
Landlord Caused Delay. Exhibit C Landlord Indemnified Parties ........................................ 10
Sample 1
Landlord Caused Delay. As used in this Lease, "Landlord Caused Delay" shall mean any actual delay resulting from the acts or omissions of Landlord or Construction Manager which causes the Substantial Completion of the Premises to occur after January 1, 2003 (except to the extent such Landlord Caused Delay results from the occurrence of a Tenant Delay), including, but not limited to, (i) failure of Landlord to timely approve or disapprove any Construction Drawings; and (ii) delays due to the acts or failures to act of Landlord, Construction Manager, or their agents and/or contractors with respect to payment of the Tenant Improvement Allowance and/or any cessation of work upon the Tenant Improvements as a result thereof.
Sample 1
Landlord Caused Delay. As used herein, “Landlord Caused Delay” shall mean only an actual delay resulting from the acts or omissions of Landlord including, but not limited to (i) failure of Landlord to timely approve or disapprove any Construction Drawings; or (ii) material interference by Landlord, its agents or contractors with the completion of the Tenant Improvements and which stop, hinder or delay construction of the Tenant Improvements and/or delivery and installation of furniture or equipment in the Building by Tenant or any material interference with access by Tenant, its agents and contractors to the Building or any Building facilities (including loading docks and freight elevators) or service (including temporary power and parking areas as provided herein) during or after construction hours.
Sample 1
Landlord Caused Delay 
Sample 1Sample 2

Related to Landlord Caused Delay

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant’s Termination Right If the part of the Buildings or the Real Property so acquired or condemned contains a substantial part of the total area of the portion of the Premises located in such Building immediately prior to such acquisition or condemnation, or if, by reason of such acquisition or condemnation, Tenant no longer has reasonable means of access to the Premises, Tenant may terminate this Lease as to such portion of the Premises by notice to Landlord given within 60 days following the date upon which Tenant received notice of such acquisition or condemnation; provided, however, that if the portion of the Premises so affected shall be the Music Hall, then Tenant’s right of termination shall apply to the whole of the Premises. Furthermore, if by virtue of the nature of the space in the Music Hall which is acquired or condemned, the space remaining in the Music Hall after giving effect to such acquisition or condemnation cannot economically be used for its intended purpose, following the date upon which Tenant received notice of such acquisition or condemnation, Tenant may terminate this Lease by notice to Landlord. If Tenant so notifies Landlord, this Lease shall terminate and the Term shall end and expire upon the date set forth in the notice as to the portion of the Premises covered thereby, which date shall not be more than 30 days following the giving of such notice. If a part of the Premises shall be so acquired or condemned and this Lease and the Term shall not be terminated in accordance with this Section, Landlord, at Landlord’s expense but without requiring Landlord to spend more than it collects as an award, shall, subject to the provisions of any Mortgage or Superior Lease, restore such portion of the Premises not so acquired or condemned to a self-contained unit substantially equivalent (with respect to character, quality, appearance and services) to that which existed immediately prior to such acquisition or condemnation, to the extent commercially practicable to do so, in which case Tenant shall be obligated to restore Tenant’s Property relating to such portion of the Premises to the condition which existed immediately prior to such acquisition or condemnation.

  • Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.

  • Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.

Time is Money Join Law Insider Premium to draft better contracts faster.