Excusable Delays. Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Excusable Delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.
Excusable Delays. Consultant shall not be liable for damages, including liquidated damages, if any, caused by delay in performance or failure to perform due to causes beyond the control of Consultant. Such causes include, but are not limited to, acts of God, acts of the public enemy, acts of federal, state or local governments, acts of District, court orders, fires, floods, epidemics, strikes, embargoes, and unusually severe weather. The term and price of this Agreement shall be equitably adjusted for any delays due to such causes.
Excusable Delays. Neither party shall be responsible for delays or lack of performance resulting from acts beyond the reasonable control of the party or parties. Such acts shall include, but not be limited to, acts of God, fire, strikes, material shortages, compliance with laws or regulations, riots, acts of war, or any other conditions beyond the reasonable control of a party.
Excusable Delays. Neither party will be liable for a failure to perform that arises from causes or events beyond its reasonable control and without its fault or negligence, including but not limited to acts of God or the public enemy, actions by any domestic or foreign governmental authority (whether valid or invalid), fires, riots, wars, sabotage, acts of terrorism, labor problems (including lockout strikes and slowdowns), or inability to obtain materials. The affected party shall give written notice of such delay, including the anticipated duration thereof, to the other party within ten (10) days of the beginning of the delay. If Seller is the affected party, Seller shall take all reasonable action, including, but not limited to, utilizing temporary production facilities or a temporary workplace, or moving existing tooling to third party production facilities in order to ensure that the supply of goods and/or services meets the requirements of the Purchase Order. During the period of such delay or failure to perform by Seller, Buyer may purchase goods from other sources and reduce its schedule to Seller by such quantities without any liability. If requested by Xxxxx, Seller shall, within ten (10) days of such request, provide adequate assurances that the delay will not exceed thirty (30) days. If the delay lasts more than thirty (30) days or Seller does not provide adequate assurances that the delay will cease within thirty (30) days, Buyer may immediately cancel the Purchase Order without liability.
Excusable Delays. The CONTRACTOR shall not be considered in default by reason of any failure in performance if such failure arises out of causes reasonably beyond the control of the CONTRACTOR or its sub- Contractors and without their fault or negligence. Such causes include, but are not limited to: acts of God; natural or public health emergencies; labor disputes; freight embargoes; and abnormally severe and unusual weather conditions. Upon the CONTRACTOR’S request, the COUNTY shall consider the facts and extent of any failure to perform the work and, if the CONTRACTOR’S failure to perform was without it or its sub-Contractor’s fault or negligence, the Contract Schedule and/or any other affected provision of this Contract shall be revised accordingly; subject to the COUNTY’S right to change, terminate, or stop any or all work at any time.
Excusable Delays. In the event that performance on the part of any party hereto shall be delayed or suspended as a result of circumstances beyond the reasonable control and without the fault and negligence of said party, none of the parties shall incur any liability to the other parties as a result of such delay or suspension. Circumstances deemed to be beyond the control of the parties hereunder shall include, but not be limited to, acts of God or of the public enemy; insurrection; acts of the Federal Government or any unit of State or Local Government in either sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes, freight embargoes or delays in transportation; to the extent that they are not caused by the party's willful or negligent acts or omissions and to the extent that they are beyond the party's reasonable control.
Excusable Delays. Neither party shall be liable for its delay or failure to perform any obligation under and in accordance with this Contract, if the delay or failure arises out of fires, floods, earthquakes, epidemics, quarantine restrictions, other natural occurrences, strikes, lockouts (other than a lockout by the party or any of the party's Subcontractors), freight embargoes, terrorist acts, insurrections or other civil disturbances, or other similar events to those described above, but in each case the delay or failure to perform must be beyond the control and without any fault or negligence of the party delayed or failing to perform (these events are referred to in this provision as "Force Majeure Events"). Notwithstanding the foregoing, a delay or failure to perform by a Subcontractor of CONTRACTOR shall not constitute a Force Majeure Event, unless the delay or failure arises out of causes beyond the control of both CONTRACTOR and Subcontractor, and without any fault or negligence of either of them. In such case, CONTRACTOR shall not be liable for the delay or failure to perform, unless the goods or services to be furnished by the Subcontractor were obtainable from other sources in sufficient time to permit CONTRACTOR to perform timely. As used in this Contract, the term "Subcontractor" means a subcontractor at any tier. In the event CONTRACTOR’S delay or failure to perform arises out of a Force Majeure Event, CONTRACTOR agrees to use commercially reasonable best efforts to obtain the goods or services from other sources, and to otherwise mitigate the damages and reduce the delay caused by the Force Majeure Event.
Excusable Delays. The dates and times by which either Party is required to perform any obligation under this Agreement shall be postponed automatically to the extent, for the period of time, that the Party is prevented from so performing by circumstances beyond its reasonable control. Said circumstances shall include acts of nature, strikes, lockouts, riots, acts of war, epidemics, government regulations imposed after the fact, fire, communications failures, power failures, earthquakes or other disasters.
Excusable Delays. Except with respect to defaults by subproviders, the Surveyor will not be considered in default for any failure that arises out of causes beyond the control and without the negligence of the Surveyor. These include acts of God or the public enemy, acts of the Government in its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
