Established. The Construction Manager and the City acknowledge that in the event that the Construction Manager fails to achieve Substantial Completion or Final Completion of the Project by the dates established therefore in the applicable GMP Amendment, as adjusted, the City will incur substantial damages and the extent of such damages shall be incapable of accurate measurement. Nonetheless, the Parties acknowledge that on the date of this Agreement, the amount of liquidated damages set forth below represents a good faith estimate as to the actual potential damages that the City would incur as a result of late Substantial Completion or Final Completion of the Project. Such liquidated damages shall be the sole and exclusive remedy of the City for late completion of the Project, and the City hereby waives all other remedies available at law or in equity with respect to losses resulting from late completion. The amount of the liquidated damages calculated hereunder does not include any penalty.
Established. The Job Order Contractor and the City acknowledge that in the event that the Job Order Contractor fails to achieve Substantial Completion or Final Completion of the Project by the dates established therefore in the applicable Job Order Schedule, as adjusted, the City will incur substantial damages and the extent of such damages shall be incapable of accurate measurement. Nonetheless, the Parties acknowledge that on the date of this Contract, the amount of liquidated damages set forth below represents a good faith estimate as to the actual potential damages that the City would incur as a result of late Substantial Completion or Final Completion of the Job Order. Such liquidated damages shall be the sole and exclusive remedy of the City for late completion of the Job Order, and the City hereby waives all other remedies available at law or in equity with respect to losses resulting from late completion. The amount of the liquidated damages calculated hereunder does not include any penalty.
Established. The Parties hereby establish the Lower Colorado River Multi-Species Conservation Program Steering Committee whose initial Members have been divided in to seven Participant Groups and are identified as:
Established. The scope of this waiver is intended to be all-encompassing of any and all disputes that may be filed in any court and that relate to the subject matter of this transaction, including contract claims, tort claims, breach of duty claims and all other common law and statutory claims. Each party hereto acknowledges that this waiver is a material inducement to enter into a business relationship, that each has already relied on this waiver in entering into this Agreement, and that each will continue to rely on this waiver in their related future dealings. Each party hereto further warrants and represents that it has reviewed this waiver with its legal counsel and that it knowingly and voluntarily waives its jury trial rights following consultation with legal counsel. THIS WAIVER IS IRREVOCABLE, MEANING THAT IT MAY NOT BE MODIFIED EITHER ORALLY OR IN WRITING (OTHER THAN BY A MUTUAL WRITTEN WAIVER SPECIFICALLY REFERRING TO THIS SECTION 13.24 AND EXECUTED BY EACH OF THE PARTIES HERETO), AND THIS WAIVER SHALL APPLY TO ANY SUBSEQUENT AMENDMENTS, RENEWALS, SUPPLEMENTS OR MODIFICATIONS TO THIS AGREEMENT OR ANY OF THE OTHER LOAN DOCUMENTS OR TO ANY OTHER DOCUMENTS OR AGREEMENTS RELATING TO THE LOANS MADE HEREUNDER. In the event of litigation, this Agreement may be filed as a written consent to a trial by the court.
Established. Any loans granted or renewed shall conform with the requirements of Section 72(p) of the Internal Revenue Code, 26 U.S.C.1 et seq. Such loan program shall be established in writing by the Board of Trustees, and must include, but need not be limited to the following:
Established. There is hereby established, by the execution of this Agreement, the “Fencing Consortium” as a joint powers entity formed pursuant to Minnesota Statutes, section 471.59, which is to be managed and operated by the Board pursuant to the terms of this Agreement.
Established. There is hereby established the “Fencing Consortium Joint Board.” The Board shall consist of five Directors elected by the Members in accordance with this Article. Directors shall serve without compensation from the Fencing Consortium. The Director positions shall be assigned as follows:
Established. New Year's Day, Xxxxxx Xxxxxx Xxxx Day, the third Monday in February (designated as Washington-Lincoln Day"), Memorial Day, Independence Day, Labor Day, Veteran's Day (floating holiday to be scheduled in advance; if worked, not at overtime rate), Thanksgiving Day, the day after Thanksgiving, Christmas Eve, Christmas Day and, individually, an employee's birthday shall be designated as holidays with pay.
Established. HEADQUARTERS The Carrier and the employees will continue the local practice discussing and agreeing amongst themselves to any change of headquarters assignments. The headquarters of employees will not be changed without first giving the affected employees five (5) working days written, posted notice. The headquarters of employees will not be changed more often than every thirty (30) days. Any temporary headquarters of employees will be equipped with lockers, bathrooms and washroom facilities, proper heating, electrical fixtures, table and chairs and will be inspected prior to use.
