Architect definition

Architect means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms “architect” and “engineer” shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect’s authority is as set forth elsewhere in this contract.

Split View

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Get StartedBook a Demo

Architect. “Engineer,” or “A/E” means a person or entity lawfully entitled to practice architecture or engineering, representing Owner within the limits of its delegated authority.

Architect means the Architect appointed or to be appointed from time to time by Promoter for the purpose of planning, designing and supervision of the construction of the Building(s).

Examples of Architect in a sentence

• Contractor shall furnish to Owner (and, if directed by the Owner, Contractor shall furnish a copy to the Architect) monthly applications for payment in such form as may be approved by the Owner not later than the 30th day of the month (“Application for Payment”).

• The Owner may delegate to the Architect some of its rights or responsibilities in this Agreement.

• The Architect has no authority, over its individual signature, to authorize any additional or changed Work that would require an increase in the Contract Sum or an extension of the Completion Dates.

• All Drawings, Specifications and copies thereof furnished by the Architect are and shall remain the property of the Owner.

• The Contractor, Subcontractors, Sub-subcontractors and material or equipment suppliers are granted a limited license to use and reproduce applicable portions of the Drawings, Specifications and other documents prepared by the Architect appropriate to and for use in the execution of their Work under the Contract Documents.

More Definitions of Architect

Architect or “Architect/Engineer” means any person or firm employed by the Commission for the purpose of designing the project.

Architect means a holder of a license, a certificate of practice, or a temporary license under the Architect’s Act as defined in the Building Code.

Architect means the architect/s appointed by the Seller from time to time for the purposes of the Development;

Architect means the person or other entity engaged by for performance of the work. The Contractor shall also the PHA to perform architectural, engineering, design, furnish all necessary water, heat, light, and power not

Architect means Architect/ Architectural Consultant appointed by the Bank for the Project.

Architect means a member of the project team who is a New Mexico licensed architect and is responsible for the architectural services.

Architect means the person so designated in writing by the Commissioner in the Notice to Proceed or the Order to Work to act as such in relation to this Contract, including a private Architect or Engineer or Project Manager, as the case may be. Subject to written approval by the Commissioner, the Engineer, Architect or Project Manager may designate an authorized representative.