Design-Builder definition

Design-Builder means the Person/Firm(s)/Joint Venture selected pursuant to the RFP that enters into the Contract with the Department to design and construct the Project.

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Design-Builder means the Person selected pursuant to the RFP that enters into the Contract with the Department to design and construct the Project (also referred to as the “Design-Build Team”).

Design-Builder means the Design- Builder or the Design-Builder’s authorized representative.

Examples of Design-Builder in a sentence

The Design-Builder shall confine operations at the site to areas permitted by applicable laws, statutes, ordinances, codes, rules and regulations, lawful orders of public authorities, and the Design-Build Documents, and shall not unreasonably encumber the site with materials or equipment.
If the Owner’s inspection discloses any item, whether or not included on the Design-Builder’s list, which is not sufficiently complete in accordance with the Design-Build Documents so that the Owner can occupy or utilize the Construction Work or that would prevent use of the Project by Owner, the Design-Builder shall, before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by the Owner.
Nothing herein, including any review by Owner or Owner’s separate consultants, shall shift such responsibility from Design-Builder to Owner.
Prior to submittal of the initial proposed Substantial Completion Certificate, Design-Builder will prepare and deliver to Owner a comprehensive written list setting forth all of the items that remain to be performed in order to complete the Work, provided such items of Work on such list shall only be items that are (i) minor in nature, (ii) not related to the functionality, utility, operation or restoration Work, and (iii) not related to the compliance of any such Work with any Applicable Laws.
The Design-Build Documents shall not be construed to create a contractual relationship of any kind between any persons or entities other than the Owner and the Design-Builder (although the Owner does not waive any third-party beneficiary rights or rights to assignment it may otherwise have as to the Architect, Consultants, or Subcontractors of any tier).

More Definitions of Design-Builder

Design-Builder means the entity, whether natural person,

Design-Builder means the entity that enters into the Design-Build Agreement with the Owner and who has direct responsibility to design and build the Project, as identified in the Proponent’s RFQ Response and as may have been changed pursuant to the RFQ or as may be changed pursuant to this RFP.

Design-Builder means the entity, whether natural person, partnership, joint stock company, corporation, trust, professional corporation, business association, or other legal business entity or successor, that proposes to design and construct any public project, who is registered pursuant to the provisions of P.L.1999, c.238 (C.34:11-56.48 et seq.), and classified by the New Jersey Division of Property Management and Construction or the New Jersey Department of Transportation, where applicable, to perform work on a design-build project.

Design-Builder means a proposer that has entered into a

Design-Builder means a person who proposes to design and construct a project in accordance with the requirements of section 16C.33.

Design-Builder means the design-build firm that proposes to design and build a project governed by the procedures of this section.

Design-Builder of a Respondent means an individual, corporation, joint venture, partnership or other legal entity who will have the direct responsibility to design and build the Project, as described in the Respondent’s Response and as may be changed pursuant to this RFQ.