Submission and Approval. The Contractor’s Submittals must comply with the Contract Documents. The Contractor shall review and approve all Submittals prior to submission. The Contract Documents shall specify when shop drawings or submittals require the seal of a specialty consultant. The Contractor shall submit copies of Submittals as required by the Contract Documents for the Work of the various trades. The Design Professional shall review, approve, or take other appropriate action with respect to shop drawings, samples, or other submissions of the Contractor, including, but not limited to, confirming conformance with the design concept of the Project and with the Contract Documents. The Design Professional shall respond to and return said items to the Contractor within fourteen calendar days from receipt provided that the Submittals are submitted by the Contractor in accordance with the required Submittal schedule. The Design Professional shall review and give comment or approval to Submittal schedule within fourteen calendar days from receipt. Large submittal documents may require longer review times, e.g., submittals with over fifty sheets of drawings. If, because of events beyond its reasonable control, the Design Professional is not able to meet the specified time period, then it is entitled to ask for additional time from the Owner. The Contractor shall make all corrections required by the Design Professional and furnish such corrected copies as may be needed. If the Contractor believes that any corrections required by the Design Professional constitute a change to the contract, the Contractor shall immediately notify the Design Professional and Owner and request instructions. By forwarding the approved Submittals to the Design Professional, the Contractor represents that the Contractor has determined and verified materials, field measurements, and field construction criteria related thereto, or will do so, and has checked and coordinated the information contained within such Submittals with the requirements of the Work and of the Contract Documents. The Design Professional’s approval of Submittals shall not relieve the Contractor from the responsibility for errors of any sort in Submittals or schedules. The Contractor shall perform no portion of the Work for which the Contract Documents require Submittals until the Design Professional has approved the respective Submittal. The Contractor shall maintain at the Site one copy of all approved Submittals.
Submission and Approval. The Design-Builder’s Submittals must comply with the Contract Documents. The Design-Builder shall review and approve all Submittals prior to submission. The Contract Documents shall specify when shop drawings or submittals require the seal of a specialty consultant. The Design-Builder shall submit copies of Submittals as required by the Contract Documents for the Work of the various trades. The Design-Builder shall perform no portion of the Work for which the Contract Documents require Submittals until the Design Professioanl has approved the respective Submittal. The Design-Builder shall maintain at the Site one copy of all approved Submittals.
Submission and Approval. Seller may, from time to time, submit a Credit File or Loan File to ArcHome for approval in accordance with the Seller’s Guide. All submissions must be consistent for the loan types, programs and limitations as further defined in the Seller’s Guide and/or this Agreement.
Submission and Approval. 4.1 Upon WEPCo’s confirmation of the New Project Request, WEPCo will (pursuant to Paragraph 4.1) produce outline proposals for New Projects, which develop and are consistent with the SDP where so requested. This is known as the Stage 1 Submission.
Submission and Approval. A. No Work shall be undertaken until its design has been submitted to and approved by the RDA. Following approval, the Participant shall contract for the Work within one hundred eighty (180) days from the date of approval by the RDA Grant Review Committee.
Submission and Approval. A. No Work shall be undertaken until the proposed design has been submitted to and approved by the RDA.
Submission and Approval. General Contractor and Construction Contract Tenant shall obtain Agency approval of the proposed General Contractor and Construction Contract. Within thirty (30) days of the Effective Date and in any event, prior to Tenant entering into Construction Contract with General Contractor. Action Date
Submission and Approval. Maintenance Contractor, within 90 Days after issuance by TxDOT of Maintenance NTP1, shall submit to TxDOT, for TxDOT’s review and approval, a Maintenance Transition Plan as described in Section 0208 of Exhibit 2.
Submission and Approval. Correspondent may, from time to time, submit a Credit File or Loan File to DIME for approval in accordance with Dime Correspondent Manual.
Submission and Approval. Any scientific publication or presentation by either party with respect to the Product, including publications relating to clinical studies, will be approved by the other party prior to publication or presentation, such approval not to be unreasonably delayed or withheld. Due regard will be given to each party's legitimate interests, i.e., protection of confidential information, commercialization of the Product, etc. Any proposed publications which are to make public any findings, data or results of the studies relating to the Product will be provided to the other party at least thirty (30) days prior to submission for publication for the other party's approval, except that abstracts may be provided seven (7) days prior to submission for publication.
