Relief for Force Majeure Sample Clauses

Relief for Force Majeure. If either Party is unable, wholly or in part, to perform or comply with any obligation hereunder, and if such inability shall have been occasioned by or as a consequence of any event of Force Majeure, the obligations of such Party, insofar only as its obligations are affected by the event of Force Majeure, shall be suspended for so long as the event of Force Majeure continues to prevent the performance of or compliance with such obligation and for such time thereafter as such Party may reasonably require to fulfill such obligation.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Relief for Force Majeure. 28. [ * ] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 24B-2 OF THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED. Commercial Licence Agreement If a party is wholly or partly unable to carry out its obligations under this Agreement (other than an obligation to pay money) because of Force Majeure, the obligations of that party will be suspended provided that:
Sample 1Sample 2
Relief for Force Majeure. Except for a Party’s obligation to make payments due under the Agreement, as stated in Section 9.4, Article 14 is soleand exclusive excuse for non-performance under this agreement. Iif by reason of Force Majeure a Party is unable, wholly or partially, to perform any of its obligations, then a Party affected by the Force Majeure shall be relieved of its obligations to the extent of the inability so caused.,for a period of sixty (60) Days,in the aggregate, during any twelve Month period, but for no longer period. After the sistieth Day, the Parties shall be obligated to perform. If deliveries for a Transaction are to be made through an inventory transfer on a pipeline or in a storage facility, an interruption, curtailment or prorationing of transportation or storage service will not constitute a Force Majeure unless the pipeline or storage facility interrupts, curtails or prorates inventory transfer service for all of its firm customers at that point. In addition, demand charges incurred by one Party for the benefit of the other Party in respect of any Transaction shall not be waived during any period of Force Majeure and shall, notwithstanding such Force Majeure, be subject to reimbursement by the Party for whose benefit they were incurred.
Sample 1
Relief for Force Majeure. Uncontrollable Circumstances; Change in Law. Neither Party shall be liable to the other Party for breach or for failure or delay in the performance of its obligations hereunder caused by any act or occurrence beyond its reasonable control, including, but not limited to: fires; floods; strikes (except any strikes involving a Party’s personnel); a change in Federal, State, or local law or ordinance; orders or judgments of any Federal, State or local court, administrative agency or governmental body; change in permit conditions or requirements; accidents; extreme weather conditions including, for example, hurricanes, tornadoes, unusually high amounts of precipitation, unusual extremes of temperature or wind, or unusually extended periods of adverse weather conditions; acts of war, aggression or terrorism (foreign or domestic); equipment failure (other than due to the inadequate maintenance thereof); and acts of God. It is specifically understood that, without limitation, none of the following acts, events or circumstances shall constitute an act or occurrence beyond a Party’s reasonable control: (i) reasonably anticipated weather conditions normal for the region in which the work is performed or (ii) any failure to pay any sums in accordance with the terms of this Agreement. Whenever the provisions of this Section are believed to apply, the Party relying thereon shall give prompt notice to the other Party of the circumstances, the basis for applicability of this Section and the time required to cure such breach or delay. Contractor shall promptly provide notice of the need, if any, for additional compensation or for renegotiation of terms in order to mitigate the effects of such event or to comply with a change in law or regulation or interpretation thereof. Contractor shall be entitled to additional time and compensation if such event delays performance into a season different from that assumed when this Agreement was executed. Contractor and City shall use reasonable best efforts to agree on appropriate mitigating actions under the circumstances.
Sample 1
Relief for Force Majeure. If a party is wholly or partly unable to carry out its obligations under this Agreement (other than an obligation to pay money) because of Force Majeure, the obligations of that party will be suspended provided that:
Sample 1
Relief for Force Majeure. The suspension of performance due to a Force Majeure Event shall be of no greater scope and no longer duration than reasonably required and the Party suffering the Force Maj xxxx shall use commercially reasonable efforts to remedy its inability to perform. If such suspension shall have occurred, the Project Schedule shall be extended by a period equal to the amount of time (including a reasonable period for demobilization and remobilization) as demonstrated by Contractor to be necessary for Contractor to make up for the delay. Contractor shall receive an equitable adjustment in the Contract Price.
Sample 1
Relief for Force Majeure. If a Party is wholly or partly unable to carry out its obligations under this Agreement (other than an obligation to pay money) due to Force Majeure, the obligations of that Party will be suspended provided that: (a) within a reasonable time after the occurrence of Force Majeure, the Party gives the other Party a written notice specifying the Force Majeure; (b) the relevant obligations will be suspended only to the extent that the obligations are affected by Force Majeure; (c) the relevant obligations will be suspended during, but no longer than, the continuance of the Force Majeure, and such further period as is reasonable in the circumstances; and (d) the Party giving the notice uses its best efforts to promptly axxxx the Force Majeure.
Sample 1
AutoNDA by SimpleDocs
Relief for Force Majeure 
Sample 1

Related to Relief for Force Majeure

  • Termination for Force Majeure In the event of a force majeure that lasts longer than thirty (30) days from the date that a Party claiming relief due to the force majeure event gives notice to the other Party, the Party not claiming relief under the force majeure event may terminate this Agreement upon written notice to the other Party. For the avoidance of doubt, the COVID-19 pandemic does not constitute a force majeure event.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon, and the obligation of the party giving such notice, so far as it is affected by such Force Majeure, shall be suspended during the continuance of the inability then claimed, except as hereinafter provided, but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. Choice of Law The Agreement between the Vendor and TIPS/ESC Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. Venue, Jurisdiction and Service of Process Any Proceeding arising out of or relating to this procurement process or any contract issued by TIPS resulting from or any contemplated transaction shall be brought in a court of competent jurisdiction in Camp County, Texas and each of the parties irrevocably submits to the exclusive jurisdiction of said court in any such proceeding, waives any objection it may now or hereafter have to venue or to convenience of forum, agrees that all claims in respect of the Proceeding shall be heard and determined only in any such court, and agrees not to bring any proceeding arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction in any other court. The parties agree that either or both of them may file a copy of this paragraph with any court as written evidence of the knowing, voluntary and freely bargained for agreement between the parties irrevocably to waive any objections to venue or to convenience of forum. Process in any Proceeding referred to in the first sentence of this Section may be served on any party anywhere in the world. Venue for any dispute resolution process, other than litigation, between TIPS and the Vendor shall be located in Camp or Xxxxx County, Texas.

  • Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event.

  • Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:

  • MAJEURE 24.1 Neither Partner shall be entitled to bring a claim for a breach of obligations under this Agreement by the other Partner or incur any liability to the other Partner for any losses or damages incurred by that Partner to the extent that a Force Majeure Event occurs and it is prevented from carrying out its obligations by that Force Majeure Event.

Time is Money Join Law Insider Premium to draft better contracts faster.