11Arbitration Sample Clauses

11Arbitration. Except as provided in Section 14.1.10, any other claims, disputes, disagreements or other matters in controversy between the Owner and the Design-Builder arising out of, or related, in any manner, to the Design-Build Documents, or the interpretation, clarification or enforcement thereof, shall be resolved by arbitration conducted by a single Arbitrator in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association ("AAA") in effect as of the date that a Demand for Arbitration is filed, except as expressly modified herein. The locale for any arbitration commenced hereunder shall be the regional office of the AAA closest to the Project site or at a location as mutually agreed by the parties. The award rendered by the Arbitrator shall be final and binding upon the Owner and the Design-Builder, as well as any other parties joined in the proceedings. In connection with any arbitration proceeding commenced hereunder, the discovery rights and procedures provided for in California Code of Civil Procedure §1283.05 shall be applicable, and the same shall be deemed incorporated herein by this reference. A Demand for Arbitration shall be filed and served within a reasonable time after the occurrence of the claim, dispute or other disagreement giving rise to the Demand for Arbitration, but in no event shall a Demand for Arbitration be filed or served after the date when the institution of legal or equitable proceedings based upon such claim, dispute or other disagreement would be barred by the applicable statute of limitations. In the event more than one Demand for Arbitration is made by either the Owner or the Design-Builder, all such controversies shall be consolidated into a single arbitration proceeding, unless otherwise agreed to by the Owner and the Design-Builder. The Design-Builder's Surety, the Architect, Consultants, Contractor and/or Subcontractors or material suppliers to the Design-Builder and other third parties may be permitted to join in and be bound by an arbitration commenced hereunder if required by the terms of their respective agreements with the Design-Builder, except to the extent that such joinder would unduly delay or complicate the expeditious resolution of the claim, dispute or other disagreement between the Owner and the Design-Builder, in which case an appropriate severance order shall be issued by the Arbitrator. The expenses and fees of the Arbitrator shall be divided equally among the parties to th...
Sample 1
AutoNDA by SimpleDocs
11Arbitration. If the Parties are unable to resolve any disputes arising under or in connection with this Agreement as described above in Section 15.10, then, all such disputes shall be submitted to and finally settled by the International Court of Arbitration of the ​ ​ [***] Certain information in this document has been excluded pursuant to Regulation S-K, Item (601)(b)(10). Such excluded information is both (i) not material and (ii) the type that the Registrant treats as private or confidential. ​ International Chamber of Commerce in accordance with the current Rules of Arbitration of the International Chamber of Commerce as then in effect by one or more arbitrators appointed in accordance with said Rules. The seat, or legal place, of arbitration shall be New York City, New York, USA. The language to be used in the arbitral proceedings will be English. The arbitration award shall be final and binding on the Parties, and the Parties undertake to carry out any award without delay. Judgment upon the award rendered by such arbitrator(s) may be entered by any court or forum having jurisdiction. The content of all arbitration proceedings and any rulings or awards of the arbitrator(s) under this Section 15.11 shall be deemed Confidential Information of both Parties; provided that in addition to disclosures permitted by Section 9.3, disclosure shall be authorized (i) to the extent required to protect or pursue a legal right, or enforce or challenge an award in bona fide legal proceedings before a state court or other judicial authority, (ii) where needed for the preparation or presentation of a claim or defense in the arbitration, or (iii) by order of the arbitral tribunal upon application of a Party. Notwithstanding the Parties’ agreement to arbitrate, unless the Parties agree in writing in any particular case, claims and disputes between the Parties relating to or arising out of, or for which resolution depends in whole or in part on a determination of the interpretation, scope, validity, enforceability or infringement of any Patents shall not be subject to arbitration under this Agreement, and the Parties may pursue whatever rights and remedies may be available to them under law or equity, including litigation in a court of competent jurisdiction, with respect to such claims and disputes.
Sample 1
11Arbitration. All disputes arising out of, or in connection with, this Agreement, or in respect of any legal relationship associated with it or derived from it, will be finally resolved by arbitration administered by [CDR Canada Inc. OR select other arbitral institution] under [its Canadian Arbitration Rules OR select other rules]. The place of arbitration will be [insert city and jurisdiction]. The language of the arbitration will be [insert].
Sample 1

Related to 11Arbitration

  • Mediation/Arbitration Employee agrees that prior to filing any motion or claim against the Company or any of its employees, Employee will offer to engage in informal mediation. Each party shall bear its own costs of mediation and one-half of the cost of the mediator. Additionally, any claim by either party arising out of or related to this Agreement, or its breach, or related in any way to Employee's employment or its termination (except claims of employment discrimination under local, state or federal laws, and requests for equitable relief under Section 9 above), shall be settled by arbitration using a single arbitrator and administered by the American Arbitration Association under its Employment Dispute Resolution Rules. Any arbitration shall take place in Seattle, Washington, and the parties waive the right to a trial de novo or appeal, excepting only for the purpose of enforcing the arbitrator's decision, for which purpose the parties agree that the Superior Court for King County, Washington shall have jurisdiction. The nature, proceedings and results of the mediation or arbitration shall be kept confidential and kept from public disclosure to the extent possible.

  • No Arbitration Disputes involving this contract, including the breach or alleged breach thereof, may not be submitted to binding arbitration (except where statutorily authorized), but must, instead, be heard in a court of competent jurisdiction of the State of New York.

  • Arbitration Disputes arising under or in connection with this Agreement that are not resolved pursuant to Section 5.1, including requests for specific performance, will be resolved through binding arbitration conducted pursuant to the rules of the International Court of Arbitration of the International Chamber of Commerce. The arbitration will be conducted in the English language and will occur in Los Angeles County, California. Any arbitration will be in front of a single arbitrator, unless (i) ICANN is seeking punitive or exemplary damages, or operational sanctions, (ii) the parties agree in writing to a greater number of arbitrators, or (iii) the dispute arises under Section 7.6 or 7.7. In the case of clauses (i), (ii) or (iii) in the preceding sentence, the arbitration will be in front of three arbitrators with each party selecting one arbitrator and the two selected arbitrators selecting the third arbitrator. In order to expedite the arbitration and limit its cost, the arbitrator(s) shall establish page limits for the parties’ filings in conjunction with the arbitration, and should the arbitrator(s) determine that a hearing is necessary, the hearing shall be limited to one (1) calendar day, provided that in any arbitration in which ICANN is seeking punitive or exemplary damages, or operational sanctions, the hearing may be extended for one (1) additional calendar day if agreed upon by the parties or ordered by the arbitrator(s) based on the arbitrator(s) independent determination or the reasonable request of one of the parties thereto. The prevailing party in the arbitration will have the right to recover its costs and reasonable attorneys’ fees, which the arbitrator(s) shall include in the awards. In the event the arbitrators determine that Registry Operator has been repeatedly and willfully in fundamental and material breach of its obligations set forth in Article 2, Article 6 or Section 5.4 of this Agreement, ICANN may request the arbitrators award punitive or exemplary damages, or operational sanctions (including without limitation an order temporarily restricting Registry Operator’s right to sell new registrations). Each party shall treat information received from the other party pursuant to the arbitration that is appropriately marked as confidential (as required by Section 7.15) as Confidential Information of such other party in accordance with Section 7.15. In any litigation involving ICANN concerning this Agreement, jurisdiction and exclusive venue for such litigation will be in a court located in Los Angeles County, California; however, the parties will also have the right to enforce a judgment of such a court in any court of competent jurisdiction.

  • Dispute Resolution; Arbitration This Agreement evidences a transaction involving interstate commerce. Any disputes arising from this Agreement shall be decided by binding arbitration which shall be conducted, at the request of any party, in New York, New York, before one arbitrator designated by the American Arbitration Association (the "AAA"), in accordance with the Commercial Arbitration Rules of the AAA, and to the maximum extent applicable, the United States Arbitration Act (Title 9 of the United States Code). Notwithstanding anything in this Agreement to the contrary, any party may proceed to a court of competent jurisdiction to obtain equitable relief at any time. An arbitrator shall have no authority to award punitive damages or other damages not measured by the prevailing party's actual damages. To the maximum extent practicable, an arbitration proceeding under this Agreement shall be concluded within 180 days of the filing of the dispute with the AAA. This arbitration clause shall survive any termination, amendment, or expiration of the Agreement and if any provision of this arbitration clause is found to be unenforceable, the remaining parts of the arbitration clause shall not be affected and shall remain fully enforceable.

  • Mediation and Arbitration Any controversy, dispute or claim arising out of or relating to this Agreement or the performance, enforcement, breach, termination or validity thereof, including the determination of the scope of this Agreement to arbitrate, shall first be submitted to non-binding mediation and shall thereafter be determined by final binding arbitration, and not litigation, the agreed venue for mediation and arbitration being in Houston, Texas. The mediation process shall be administered by a mutually acceptable mediator selected in accordance with the Commercial Mediation Rules of the American Arbitration Association (“AAA”). If any dispute remains unresolved between the parties after the mediation process has been completed, either party may then submit any such unresolved dispute to final and binding arbitration pursuant to the Commercial Arbitration rules of AAA, with all matters related to the enforceability of this arbitration agreement and any award rendered pursuant to this agreement to be governed by the Federal Arbitration Act, 9 U.S.C. Section 1-16. The Arbitration Tribunal shall be formed of three (3) arbitrators each of which shall have at least five (5) years’ experience in hotel operation, management, ownership or leasing, one (1) to be appointed by each party and the third (3rd) to be appointed by the American Arbitration Association. The arbitration panel may require and facilitate such discovery as it shall determine is appropriate in the circumstances, taking into account the needs of the parties and the desirability of making discovery expeditious and cost-effective. The arbitration panel shall be empowered to subpoena non-party and party witnesses for deposition and hearing to the full extent provided under the AAA Rules and the Federal Arbitration Act (or the applicable state arbitration statute if the arbitration panel is appointed pursuant to a petition filed in state court). The arbitration panel may also direct the production of documents and other information and the advance identification of witnesses to be called and documents to be admitted. The arbitration panel may issue orders to protect the confidentiality of proprietary information, trade secrets and other sensitive information before it is required to be disclosed in discovery. In addition to monetary damages, or in lieu thereof, the arbitration panel shall have the power to grant all equitable relief (both by way of interim relief and as a part of its final award) as may be granted by any court in the state where the Hotel is located. Monetary damage liability shall be limited to actual damages; the parties hereby waive the right to claim and/or receive punitive damages or exemplary relief. The arbitration panel shall determine whether and to what extent any party is a prevailing party and shall award attorneys’ fees and expenses associated with the arbitration proceeding to the “prevailing party, if any. All proceedings shall be reported by a certified shorthand court reporter and written transcripts of the proceedings shall be prepared and made available to the parties. The fees of the arbitration panel, together with all costs and expenses incurred in conducting the arbitration (but excluding the parties’ respective attorney, witness and related costs and expenses) shall be borne by the party against whom the arbitral award is made and shall be a (the) component of the arbitral award. The arbitration shall take place in Orlando, Florida, and shall be conducted in the English language. The arbitration award shall be final and binding upon the parties hereto and subject to no appeal. Arbitration expenses shall not be an expense in determining House Profit. Judgment upon the award rendered maybe entered into any court having jurisdiction, or applications may be made to such court for an order of enforcement.

  • Expedited Arbitration (a) The Parties may by mutual agreement refer to expedited arbitration any outstanding grievances considered suitable for this process, and shall set dates and locations for hearings of groups of grievances considered suitable for expedited arbitration.

  • Disputes; Arbitration (a) Any dispute or controversy arising under or in connection with this Agreement shall be settled exclusively by binding arbitration at Primex's corporate headquarters in accordance with the rules of the American Arbitration Association then in effect. Judgment may be entered on the arbitrator's award in any court having jurisdiction; provided, however, that the Executive shall be entitled to seek specific performance of the Executive's right to be paid during the pendency of any dispute or controversy arising under or in connection with this Agreement.

  • Mediation and Arbitration of Disputes An Addendum requiring the Mediation and/or the Arbitration of all disputes between the Parties and/or Brokers arising out of this Lease ¨ is x is not attached to this Lease. LESSOR AND LESSEE HAVE CAREFULLY READ AND REVIEWED THIS LEASE AND EACH TERM AND PROVISION CONTAINED HEREIN, AND BY THE EXECUTION OF THIS LEASE SHOW THEIR INFORMED AND VOLUNTARY CONSENT THERETO. THE PARTIES HEREBY AGREE THAT, AT THE TIME THIS LEASE IS EXECUTED, THE TERMS OF THIS LEASE ARE COMMERCIALLY REASONABLE AND EFFECTUATE THE INTENT AND PURPOSE OF LESSOR AND LESSEE WITH RESPECT TO THE PREMISES. ATTENTION: NO REPRESENTATION OR RECOMMENDATION IS MADE BY THE AMERICAN INDUSTRIAL REAL ESTATE ASSOCIATION OR BY ANY BROKER AS TO THE LEGAL SUFFICIENCY, LEGAL EFFECT, OR TAX CONSEQUENCES OF THIS LEASE OR THE TRANSACTION TO WHICH IT RELATES. THE PARTIES ARE URGED TO:

  • Dispute Resolution and Arbitration The following procedures shall be used in the resolution of disputes:

  • Disputes and Arbitration 22. Any dispute concerning a question of fact arising under this contract shall be disposed of by good faith negotiation between duly authorized representatives of the County, the Office of the State Auditor, and the Firm. Such a resolution shall be reduced to writing and a copy thereof mailed or furnished to the Firm and shall be final and conclusive. If a resolution cannot be reached, the Firm shall mail or furnish to the Board of Supervisors of the County and the Office of the State Auditor a written request for review. The Firm shall be afforded an opportunity to be heard and to offer evidence in support of his/her/its position on the issue in dispute and under review. The review will be handled under a three (3) person panel for arbitration composed of the Deputy State Auditor, the Director of Technical Assistance and the Director of the Financial and Compliance Audit Division. The decision of the Arbitration Panel of the Office of the State Auditor on the review shall be final and conclusive unless determined by a court of competent jurisdiction in Xxxxx County, State of Mississippi, to have been fraudulent, capricious, or so grossly erroneous as necessarily to imply bad faith, or not be supported by substantial evidence. Pending final decision of a dispute hereunder, the Firm shall proceed diligently with the performance of the duties and obligations of the contract.

Time is Money Join Law Insider Premium to draft better contracts faster.