PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board agrees to implement the following:
Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
PROFESSIONAL IMPROVEMENT A. The parties’ support the principle of continuing training of teachers, participation by teachers in professional organizations in the areas of their specialization, leaves for work on advanced degrees or special studies, foreign travel and participation in community educational projects.
Investigational Services This plan covers certain experimental or investigational services as described in this section. Clinical Trials This plan covers clinical trials as required under R.I. General Law § 27-20-60. An approved clinical trial is a phase I, phase II, phase III, or phase IV clinical trial that is being performed to prevent, detect or treat cancer or a life-threatening disease or condition. In order to qualify, the clinical trial must be: • federally funded; • conducted under an investigational new drug application reviewed by the Food and Drug Administration (FDA); or • a drug trial that is exempt from having such an investigational new drug application. To qualify to participate in a clinical trial: • you must be determined to be eligible, according to the trial protocol; • a network provider must have concluded that your participation would be appropriate; and • medical and scientific information must have been provided establishing that your participation in the clinical trial would be appropriate. If a network provider is participating in a clinical trial, and the trial is being conducted in the state in which you reside, you may be required to participate in the trial through the network provider. Coverage under this plan includes routine patient costs for covered healthcare services furnished in connection with participation in a clinical trial. The amount you pay is based on the type of service you receive. Coverage for clinical trials does not include: • the investigational item, device, or service itself; • items or services provided solely to satisfy data collection and that are not used in the direct clinical management; or • a service that is clearly inconsistent with widely accepted standards of care.
CENTRAL GRIEVANCE PROCESS The following process pertains exclusively to grievances on central matters that have been referred to the central process. In accordance with the School Boards Collective Bargaining Act central matters may also be grieved locally, in which case local grievance processes will apply.
Complaints Process The School shall establish and adhere to a process for resolving public complaints which shall include an opportunity for complainants to be heard. The final administrative appeal shall be heard by the School's Governing Board, except where the complaint pertains to a possible violation of any law or term under this Contract. The complaints process shall be readily accessible from the School’s website, as described in Section 11.4.1.
Request Procedure The employee shall furnish evidence to his/her immediate supervisor that leave taken in accordance with the provisions of this section is in connection with family illness. The employee shall notify his/her immediate supervisor if any of the circumstances necessitating the leave change.
Evaluation Process A. The immediate supervisor will meet with an employee at the start of the employee’s probationary, trial services, transition, and annual review period to discuss performance expectations. The employee will receive copies of their performance expectations as well as notification of any modifications made during the review period. Employee work performance will be evaluated during probationary, trial service and transition review periods and at least annually thereafter. Notification will be given to a probationary or trial service employee whose work performance is determined to be unsatisfactory.
Test procedure The engine speed shall be gradually increased from idle to the target engine speed, not exceeding the tolerance band of ±3 per cent of the target engine speed, and held constant. Then the throttle control shall be rapidly released and the engine speed shall be returned to idle. The sound pressure level shall be measured during a period of operation consisting of a maintaining constant engine speed of 1 second and throughout the entire deceleration period. The maximum sound level meter reading during this period of operation, mathematically rounded to the first decimal place, is taken as the test value.