PacifiCorp’s Right to Monitor Sample Clauses

PacifiCorp’s Right to Monitor. During the Term, Seller shall permit PacifiCorp and its advisors and consultants to:
AutoNDA by SimpleDocs
PacifiCorp’s Right to Monitor. During the Term, Seller shall permit PacifiCorp and its advisors and consultants to: Review and discuss with Seller and its advisors and consultants monthly status reports on the progress of the acquisition, design, financing, engineering, construction and installation of the Facility. Between the Effective Date and thirty (30) days following the date of Final Completion, Seller shall, on or before the tenth (10th) day of each calendar month, provide PacifiCorp with a brief monthly status report for the preceding month. Monitor the status of the acquisition, land leasing, design, financing, engineering, construction and installation of the Facility and the performance of the contractors constructing the Facility. Monitor and receive monthly updates from Seller concerning (i) the progress of Seller's negotiation and execution of contracts for the acquisition, design, financing, engineering, construction and installation of the Facility, Premises, major equipment, and warranties, and (ii) the contractors' performance and achievement of contract deliverables and all performance and other tests required to achieve Commercial Operation or contemplated by the warranty agreements between Seller and a manufacturer of the Facility’s Solar Panels and Inverters and any other material items of Facility equipment that require testing for warranty agreements to be effective. Seller shall provide PacifiCorp with at least two (2) Business Days prior notice of each such test, with the understanding that if the performance of such test is dependent on the presence of sufficient solar insolation or other variables beyond the control of Seller, the date of such test may be postponed if, on the date specified in the related notice, there is insufficient solar insolation or other circumstances beyond the control of Seller that prevent the performance of such test on the scheduled date. Seller does not herein grant PacifiCorp the right to review, comment on or approve of the terms or conditions of any contract or negotiation between Seller and a third party, the terms and conditions of each such contract or negotiation being confidential and to be determined by Seller in its sole discretion. Conversely, nothing in this Agreement shall be construed to require PacifiCorp to review, comment on, or approve of any contract between Seller and a third party. Witness initial performance tests and other tests and review the results thereof; with Seller to make best efforts to provide Pac...
PacifiCorp’s Right to Monitor. Seller will provide monthly updates to PacifiCorp concerning the construction schedule and progress of Seller regarding the acquisition, design, major equipment procurement and site delivery, financing, engineering, construction, installation, start-up and testing of the Facility, including any significant developments or delays in achieving Commercial Operation by the Scheduled Commercial Operation Date. PacifiCorp, at its own expense, shall have the right to monitor the construction, installation, start-up and testing of the Facility for compliance with this Agreement; provided, that PacifiCorp shall schedule any visit to the Premises in advance with Seller and PacifiCorp shall comply with Seller’s reasonable written health, safety and security requirements provided to PacifiCorp. Notwithstanding anything to the contrary contained herein, nothing in this Agreement will be construed to require PacifiCorp to monitor Seller’s development, design, engineering, construction, installation, start-up and testing of the Facility or to review, comment on, or approve any contract between Seller and another Person, and PacifiCorp shall have no liability to Seller for failing to advise it of any condition, damage, circumstance, infraction, fact, act, omission or disclosure discovered or not discovered by PacifiCorp or its Representatives with respect to the acquisition, design, financing, engineering, construction, installation, start-up and testing of the Facility.
PacifiCorp’s Right to Monitor. During the design, procurement, construction, installation, start up and testing of the Facility, Seller shall permit PacifiCorp and its advisors and consultants to perform such examinations, inspections, and quality surveillance as, in PacifiCorp’s reasonable judgment, are appropriate and advisable to determine that, each wind turbine has been properly commissioned and the Commercial Operation Date has been achieved. The Parties acknowledge and agree that PacifiCorp is under no obligation to perform any of these monitoring rights, and PacifiCorp acknowledges that Seller shall not be required to postpone or delay any test so long as Seller has provided prior notice to PacifiCorp of the test in accordance with Section 2.8. Any such monitoring shall occur subject to reasonable rules developed by Seller regarding Facility construction, access, health, safety, and environmental requirements, and PacifiCorp shall have no liability to Seller for failing to advise it of associated activities or omissions, including any condition, damages, circumstances, infraction, fact, act, omission or disclosure discovered or not discovered by PacifiCorp with respect to the Facility.
PacifiCorp’s Right to Monitor. During the Term, Seller will allow PacifiCorp to monitor and will provide monthly updates to PacifiCorp concerning (a) the progress of Seller regarding the acquisition, design, financing, engineering, construction and installation of the Facility, and (b) the contractors’ performance of tests required to achieve Commercial Operation. Seller must provide PacifiCorp at least one hundred and twenty (120) days prior notice of each such performance test. Notwithstanding the foregoing, nothing in this Agreement will be construed to require PacifiCorp to monitor Seller’s development of the Facility or to review, comment on, or approve any contract between Seller and a third party.‌

Related to PacifiCorp’s Right to Monitor

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.1.5. There is no legal limitation on the Owner’s right to make changes such as may be, in the Owner’s sole discretion, useful or desirable to the Project.

  • HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.

  • STUDENT’S RIGHT TO CANCEL You have the right to cancel or withdraw and receive a refund of 100% of the amount paid for institutional charges, less the STRF of $0.00, and a reasonable deposit or application fee not to exceed $250, through attendance at the first class session, or the seventh day after enrollment, whichever is later, if notice of cancellation is received on or before the right to cancel date. See table below. First Term of Enrollment 2020-2021 Academic Year Application Deadline Classes Begin Right to Cancel Date Fall Term 2020 Sept 1, 2020 Sept 8, 2020 Sept 15, 2020 Spring Term 2021 Jan 14, 2021 Jan 19, 2021 Jan 26, 2021 Summer Term 2021 June 1, 2021 June 7, 2021 June 14, 2021 To cancel, students must submit a written and signed notice of Withdrawal Form to the Registrar's Office by the right to cancel date above. The Withdrawal Form can be downloaded from xxx.xxxxxxxxxxxxxxxx.xxx/xxxxxxxxx/ student-forms. Students are not required to purchase books, supplies or equipment through Cambridge College, and the College does not offer student housing or transportation. Therefore these expenses cannot be refunded by the College. REFUNDS & REPAYMENT Students who withdraw from Cambridge College after having paid the current term charges or receiving financial aid are subject to the following refund and repayment policies. Federal guidelines mandate that tuition, fees, and other related charges are prorated based upon each student’s enroll- ment status. Tuition and fees may be refunded. No other charges are refundable. REFUNDS & REPAYMENT—STUDENTS RECEIVING TITLE IV FINANCIAL AID Exit Counseling. All borrowers of federal student loans must complete federally mandated exit counseling when gradu- ating or dropping to less than half-time enrollment status. Exit counseling prepares students for repayment. Students must do the exit counseling in its entirety, with complete and correct information; otherwise the degree, diploma, and official transcripts will be withheld. To complete the exit interview online, go to xxx.xxxxxxxxxxxx.xxx, and click on Exit Counseling. Repayment of Federal Funds. Students receiving federal financial aid, who withdraw from the College or stop attending all classes during a term before more than 60% of the term has elapsed, are subject to specific federal regulations. The amount of Title IV aid that you must repay is determined by the federal formula for return of Title IV funds as speci- fied in Section 484B of the Higher Education Act. The amount of Title IV aid that you earned during the term before you withdrew is calculated by multiplying the total aid for which you qualified by the percentage of time in the term that you were enrolled (college work-study not included). Your disbursement or repayment owed: • If less aid was disbursed to you than you earned, you may receive a late disbursement for the difference. • If more aid was disbursed to you than you earned, you will be billed for the amount you owe to the Title IV programs and any amount due to the College resulting from the return of Title IV funds used to cover College charges. Cambridge College will return the unearned aid to Title IV programs as specified by law. Students who have received federal student financial aid funds are entitled to a refund of any moneys not paid from federal student financial aid program funds (see below).

  • City's Right to Proceed In the event this contract is terminated pursuant to Paragraph 8, then the City may take over the work and prosecute the same to completion, by contract or otherwise, and Contractor and its sureties shall be liable to the City for any costs over the amount of this contract thereby occasioned by the City. In any such case, the City may take possession of, and utilize in completing the work, such materials, appliances and structures as may be on the work site and are necessary for completion of the work. The foregoing provisions are in addition to, and not in limitation of, the rights of the City under any other provisions of the contract, city ordinances, and state and federal laws.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.

  • OWNER’S RIGHT TO CLEAN UP If a dispute arises among the Design-Builder, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and will allocate the cost among those responsible.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • DXC’s Right to Inspect DXC may, at any time, inspect the software, Services, or Products and associated manufacturing processes. Inspection may occur at Supplier’s facility, plant or subcontractor’s plant. Supplier will inform its vendors and subcontractors of DXC’s right to inspect and shall secure that right for DXC if necessary.

  • STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.

Time is Money Join Law Insider Premium to draft better contracts faster.