Landlords Construction Work Sample Clauses

Landlords Construction Work. Landlord and Xxxxxx acknowledge and agree that the Project will be constructed and delivered by Landlord in two phases (referred to herein as “Phase I” and “Phase II”, respectively), each on a “turnkey” basis, subject to the terms and conditions of this Work Letter. Phase I will include the Phase I Base Building and Site Work and the Phase I Tenant Improvements (each as defined below, and collectively, the “Phase I Work”), and Phase II will include the Phase II Base Building and Site Work and the Phase II Tenant Improvements (each as defined below, and collectively, the “Phase II Work”). The Phase I Base Building and Site Work and the Phase II Base Building and Site Work are collectively referred to herein as “Landlord’s Base Building and Site Work”, the Phase I Tenant Improvements and the Phase II Tenant Improvements are collectively referred to herein as the “Tenant Improvements”, and the Phase I Work and the Phase II Work are collectively referred to as “Landlord’s Construction Work”. Xxxxxxxx’s anticipated schedules for the design, governmental approvals (i.e., building department, historical commissions, planning, etc.), development, construction and performance of Landlord’s Construction Work are attached hereto as Schedule 1 to this Work Letter (the “Landlord’s Construction Work Schedule”). The Landlord’s Construction Work Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter. Additionally, Tenant acknowledges that Landlord’s Construction Schedule with respect to the Phase II Work is conceptual and preliminary in nature, and remains subject to further revision by Landlord until such time as Landlord has received all approvals that are required from applicable governmental agencies in connection with the Phase II Work. Notwithstanding the foregoing, nothing in this Section 1.2 shall limit Tenant’s rights and remedies pursuant to Section 2.6 of the Lease.
Sample 1
AutoNDA by SimpleDocs
Landlords Construction Work. The schedule for the design and development of Landlord’s Construction Work (as defined in the Lease), including, without limitation, the time periods for preparation and review of construction documents, approvals and performance, shall be in accordance with that certain schedule prepared by Landlord and Tenant attached as Exhibit A-2 to this Work Letter (the “Landlord’s Construction Work Schedule”). The Landlord’s Construction Work Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter.
Sample 1
Landlords Construction Work. Landlord’s Construction Work shall be performed by Landlord at Landlord’s sole cost and expense in accordance with the Approved CW Plans (as defined below), the outline specifications attached hereto as Exhibit B, and the Landlord’s Construction Work Schedule, subject only to changes approved in accordance with Section 2.3.
Sample 1
Landlords Construction Work. Promptly after Landlord obtains all Governmental Approvals, a general contractor designated by Landlord (“Landlord’s Contractor”) will construct improvements in the Premises substantially in accordance with the Construction Plans (“Landlord’s Construction Work”), EXCEPT that Landlord’s Construction Work shall not include the following, all of which shall be performed by Tenant, at Tenant’s expense, (a) all work designated on the Construction Plans as “Tenant’s Work,” and (b) the installation of all of Tenant’s Property in the Premises. The term “Landlord’s Construction Work Costs” shall mean all costs incurred by Landlord in connection with Landlord’s Construction Work, including a Landlord’s construction supervisory fee not to exceed 1%of the Landlord’s Construction Work Costs (exclusive of such supervisory fee).
Sample 1
Landlords Construction Work 
Sample 1Sample 2Sample 3See All (5)

Related to Landlords Construction Work

  • Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.

  • Construction Work The regulation at 41 C.F.R. § 60-1.3 defines “construction work” as the construction, rehabilitation, alteration, conversion, extension, demolition or repair of buildings, highways, or other changes or improvements to real property, including facilities providing utility services. The term also includes the supervision, inspection, and other onsite functions incidental to the actual construction.

  • Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.

  • Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.

  • Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the "ALTERATIONS") without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than thirty (30) days prior to the commencement thereof, and which consent (as indicated in Section 29.4 below) shall not be unreasonably withheld by Landlord. However, Tenant may make (i) cosmetic changes to the finish work in the Premises, not requiring any structural or other substantial modifications to the Premises (e.g., voice/data cabling), without Landlord's prior consent, (ii) cosmetic changes to the interior of any Tenant space within the Building (e.g., changes to the carpet, wallcovering and paint) and (iii) nonstructural changes to the interior of any Tenant space within the Building (such cosmetic and nonstructural changes to be referred to hereafter collectively as the "ACCEPTABLE CHANGES") upon at least ten (10) days prior notice to Landlord but without Landlord's prior consent provided (a) with respect to the changes described in Subsection 8.1(iii) above only, such changes do not cost in excess of Two Dollars ($2.00) per usable square foot of the Premises for any one (1) job, (b) such Acceptable Changes do not affect the exterior appearance of the Building or Common Areas, the structural aspects of the Building, or any Building System or Equipment, and (c) Tenant shall perform such Acceptable Changes in a good and workmanlike manner and in conformance with any and all applicable federal, state, county or municipal laws, rules or regulations (collectively, "APPLICABLE LAWS"). At any time Tenant proposes to make Alterations which require the consent of Landlord pursuant to this Section 8.1, Tenant's notice regarding the proposed Alterations shall be provided together with plans and specifications for the Alterations, and Landlord shall approve or disapprove of the same within fifteen (15) days after Landlord's receipt thereof. The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8, and therefore, as used herein, the term "Alterations" does not refer to any tenant improvements installed pursuant to the Tenant Work Letter.

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Lessee Improvements Lessee shall not make or allow to be made any alterations or physical additions in or to the leased premises without first obtaining the written consent of Lessor, which consent shall not be unreasonably withheld. Any alterations, physical additions or improvements to the leased premises made by Lessee shall at once become the property of Lessor and shall be surrendered to Lessor upon the termination of this Lease provided that Lessee shall be entitled to retain the property listed on Exhibit A attached hereto, and provided further that, Lessor, at its option, may require Lessee to remove any physical additions and/or repair any alterations in order to restore the leased premises to the condition existing at the time Lessee took possession, reasonable wear and tear excepted, all costs of removal and/or alterations to be borne by Lessee. This clause shall not apply to moveable equipment of furniture owned by Lessee, which may be removed by Lessee at the end of the term of this Lease if Lessee is not then in default and if such equipment and furniture are not then subject to any other rights, liens and interests of Lessor.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.

  • Tenant’s Alterations (a) The construction of the initial Leasehold Improvements (as defined in Exhibit C) shall be governed by the terms of Exhibit C attached hereto and made a part hereof. Except for the Leasehold Improvements and as otherwise set forth below, Tenant shall not, and shall not permit any Tenant Agent to, cut, drill into, or secure any fixture, apparatus, or equipment, or make alterations, improvements, or physical additions of any kind to any part of the Premises (collectively, “Alterations”) without first obtaining the written consent of Landlord, which consent shall not be unreasonably withheld, conditioned, or delayed. If Landlord fails to respond to a request for consent to a proposed Alteration within 10 business days after Landlord’s receipt of such request, the request shall be deemed denied. Notwithstanding the foregoing, if Landlord fails to respond within such 10 business-day period, Tenant may thereafter send to Landlord a second written requesting approval of the proposed Alteration, which request must set forth in bold and 14-point capitalized type on the first page thereof the following statement: “SECOND AND FINAL REQUEST—LANDLORD HAS 10 BUSINESS DAYS TO RESPOND PURSUANT TO SECTION 9” (“Second Alteration Request”). If Landlord then fails to respond to the Second Alteration Request within 10 business days after receipt thereof (“Second Alteration Request Response Period”), Landlord shall be deemed to have elected to consent to the proposed Alteration, provided Tenant shall otherwise have complied with all provisions of this Lease relating to such Alterations. Notwithstanding the foregoing, if Landlord notifies Tenant in writing within the Second Alteration Request Response Period that Landlord requires additional time to review the request, then the Second Alteration Request Response Period shall be extended by an additional 10 business days. “

Time is Money Join Law Insider Premium to draft better contracts faster.