Certificate of Recognition Sample Clauses

Certificate of Recognition. The Contractor shall provide a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association prior to commencement of any work. At anytime during the term of the Contract, when requested by the owner, the Contractor shall provide such evidence of compliance by any or all of his or her Subcontractors. The Contractors and all Subcontractors Safety Plan must be submitted to the Department before the commencement of any work. Be advised that any contractor not in good standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association should do so immediately. PRICING SCHEDULE DISTRICT 4 Western Region ITEM DESCRIPTION HOURLY RATE DAILY RATE WEEKLY RATE MONTHLY RATE APPLICABLE UNIT(S) 1 Portable Welder
Sample 1
AutoNDA by SimpleDocs
Certificate of Recognition. Subject to Section 1.6 [Temporary Letter of Certification] of this Schedule 11 [Construction Safety Requirements], Project Co shall, if it is eligible to obtain such:
Sample 1
Certificate of Recognition. The contractor shall within 14 days of award of the contract, and prior to commencement of the work, provide a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association. At anytime during the Contract, when requested by the Town, the Contractor shall provide such evidence of compliance by any or all of his Subcontractors. The Town of Labrador City will strictly enforce safety requirements as per the Occupational Health & Safety Act. All items of safety apparel/equipment shall be the responsibility of the contractor.
Sample 1
Certificate of Recognition. The Contractor must provide to the College a copy of its Certificate of Recognition issued jointly by the Nova Scotia Department of Environment & Labour and an occupational health and safety organization approved by Nova Scotia Department of Environment & Labour, or a valid Letter of Good Standing from an occupational health and safety organization approved by NSCC, before beginning the Work. Updated Safety documents must be provided to the College during the term of the Agreement where Safety documents expire before completion date stated in the Agreement.
Sample 1
Certificate of Recognition. The Contractor shall provide with their Tender Submission a Letter of Good Standing under the Certificate of Recognition Program from the Newfoundland and Labrador Construction Safety Association. For those “In Process”, the letter of process should be submitted with the Tender Submission but all Contractors must have a Letter of Good Standing issued prior to the commencement of any work. Contractors failing to submit these documents with their Tender Submission, may result in Standing Offers not being issued. At anytime during the term of the Contract, when requested by the owner, the Contractor shall provide such evidence of compliance by any or all of his or her Subcontractors. The Contractors and all Subcontractors Safety Plan must be submitted to the Department before the commencement of any work.
Sample 1
Certificate of Recognition. 5.2 Metrolinx has implemented a phased-in approach for the Certificate of Recognition (CORTM) safety program for its construction projects. Throughout the Term of the Contract, the Contractor must achieve the following milestones related to CORTM certification:
Sample 1
Certificate of Recognition. Safety qualification shall be in the form of a Certificate of Recognition (“COR”) or its successor, which is relevant to the applicable industry and which is recognized by Alberta Labour, or its successor department of the provincial government of Alberta (“Workplace Health and Safety”). The Contractor shall obtain before the commencement of the Project and shall maintain throughout the duration of the Project and the O&M, a COR. The Contractor shall ensure the subcontractors listed in Schedule 17 to the DBFO Agreement maintain a COR at any time such subcontractor is providing services for the Project or the O&M.
Sample 1
AutoNDA by SimpleDocs
Certificate of Recognition. Each assuming insurer which is complying with the provisions of subdivision (a), (b), (c) or (d) of section 125.2 of this Part shall be issued a certificate of recognition as an accredited reinsurer and no ceding insurer shall take credit for reinsurance recoverables from such an assuming insurer unless such assuming insurer has a valid certificate of recognition in force. Such certificate shall have a continuous term until revoked by the superintendent. 11 NYCRR 125.8 6
Sample 1
Certificate of Recognition. Prior to the Contractor undertaking any construction work, in respect of the Project, or performing any aspect of the Existing Facilities O&M or the O&M, the Contractor shall have a valid COR for the health and safety management system(s) to be followed for the subject activity. The COR must be valid for the specific health and safety management system(s) that are to be used for the Project, the Existing Facilities O&M and the O&M, as applicable, and shall be co-signed by Alberta Human Services. The Contractor shall also ensure that any subcontractors, including those subcontractors listed in Schedule 17 of the DBFO Agreement shall have in place a valid COR for the work or services that the subcontractor is providing to the Contractor for the Project, the Existing Facilities O&M or the O&M.
Sample 1

Related to Certificate of Recognition

  • CERTIFICATE OF SERVICE I certify that I served a true and correct copy of the foregoing Consent Agreement and Final Order, which was filed on the addressees: March 18, 2021 , this day in the following manner to Copy by email to Respondent’s Representative: (Delivery Receipt Requested) Xxxxx Xxxx Vice President/Operations Manager Perfection Industries, Inc. 00000 Xxxxxx Xxxxxx Detroit, Michigan xxxxx@xxxxxxxxxxxxxxxxxxxx.xxx Copy by email to Attorney for Complainant: Richard Clarizio xxxxxxxx.xxxxxxx@xxx.xxx Copy by email to Regional Judicial Officer: Ann Coyle xxxxx.xxx@xxx.xxx XXXXXX XXXXXXXXX Digitally signed by XXXXXX XXXXXXXXX Date: 2021.03.18 15:33:51 -05'00' XxXxxx Xxxxxxxxx Date Regional Hearing Clerk

  • Certificate of Parent The Company shall have received a certificate from Parent executed by a Vice President for and on its behalf to the effect that, as of the Closing:

  • Certificate of Non-Foreign Status In order to comply with § 1445 of the Code and the applicable Treasury Regulations thereunder, in the event of the disposition by the Company of a United States real property interest as defined in the Code and Treasury Regulations, each Member shall provide to the Company an affidavit stating, under penalties of perjury, (i) the Member’s address, (ii) United States taxpayer identification number, and (iii) that the Member is not a foreign person as that term is defined in the Code and Treasury Regulations. Failure by any Member to provide such affidavit by the date of such disposition shall authorize the Manager to withhold ten percent (10%) of each such Member’s distributive share of the amount realized by the Company on the disposition.

  • Certificate of Limited Partnership The General Partner has caused the Certificate of Limited Partnership to be filed with the Secretary of State of the State of Delaware as required by the Delaware Act. The General Partner shall use all reasonable efforts to cause to be filed such other certificates or documents that the General Partner determines to be necessary or appropriate for the formation, continuation, qualification and operation of a limited partnership (or a partnership in which the limited partners have limited liability) in the State of Delaware or any other state in which the Partnership may elect to do business or own property. To the extent the General Partner determines such action to be necessary or appropriate, the General Partner shall file amendments to and restatements of the Certificate of Limited Partnership and do all things to maintain the Partnership as a limited partnership (or a partnership or other entity in which the limited partners have limited liability) under the laws of the State of Delaware or of any other state in which the Partnership may elect to do business or own property. Subject to the terms of Section 3.4(a), the General Partner shall not be required, before or after filing, to deliver or mail a copy of the Certificate of Limited Partnership, any qualification document or any amendment thereto to any Limited Partner.

  • Certificate of Conformance At Buyer’s request, a Certificate of Conformance stating the Products conform to all Order requirements shall accompany each shipment. Seller shall have available for review all sub-tier certifications for goods and processes that support the shipment.

  • Recognition of the U.S. Special Resolution Regimes (a) In the event that any Underwriter that is a Covered Entity becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer from such Underwriter of this Agreement, and any interest and obligation in or under this Agreement, will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement, and any such interest and obligation, were governed by the laws of the United States or a state of the United States.

  • Certificate of No Default A certificate signed by an appropriate officer of Borrower to the effect that: (A) no Event of Default or Unmatured Event of Default has occurred and is continuing or will result from the making of the first Loan; and (B) the representations and warranties of Borrower contained herein are true and correct as at the date of the first Loan as though made on that date.

  • Recognition of U.S. Special Resolution Regimes (a) In the event a Covered Party becomes subject to a proceeding under a U.S. Special Resolution Regime, the transfer of this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) from such Covered Party will be effective to the same extent as the transfer would be effective under the U.S. Special Resolution Regime if this Agreement (and any interest and obligation in or under, and any property securing, this Agreement) were governed by the laws of the United States or a State of the United States.

  • Certificate of Seller Seller shall have provided Purchaser a certificate, substantially in the form attached hereto as Exhibit C, signed by an authorized officer of Seller dated as of such date, applicable to the transactions contemplated by this Agreement, to the effect that: (a) each of Seller’s representations and warranties made in this Agreement and each other Transaction Document to which Seller is a party is true and correct in all material respects as of such date; (b) all of the terms, covenants, conditions and obligations of this Agreement and each other Transaction Document to which Seller is a party that are required to be complied with and performed by Seller at or prior to the Closing Date have been duly complied with and performed in all material respects; (c) the conditions set forth in Section 9.04 and Section 9.05 have been satisfied; and (d) as of the Closing Date, Seller has a Consolidated Tangible Net Worth of at least the sum of (x) $250,000,000 and (y) 50% of the proceeds from any issuance of equity on or after the date hereof by Seller, Nationstar Mortgage Holdings Inc. or any of Seller’s consolidated subsidiaries, and the Seller (considered together with the Seller’s consolidated subsidiaries) is not in default in any indebtedness in excess of $10,000,000 (individually or in the aggregate).

  • Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.

Time is Money Join Law Insider Premium to draft better contracts faster.