Review of DPR Sample Clauses

Review of DPR. (i) DMA/ Independent Engineer shall review the DPR and specifications and calculations submitted by the Developer and subject to the provisions of sub-clause (ii) herein below, communicate its/his approval within 21 (twenty one) days from the date of the receipt thereof. The DMA/ Independent Engineer may in consultation with the Developer prescribe a schedule for submission, clarifications and approval of DPR for specific components of the Project. The finalised Technical Specifications shall be part of Approved DPR.
Sample 1Sample 2
AutoNDA by SimpleDocs
Review of DPR. The Contractor shall submit the DPR including the Dredging Management Plan for review of the Independent Engineer within 75 (seventy five) days of Appointed Date. The Independent Engineer shall review the DPR submitted by the Contractor and provide its observations and suggestions on the same including the observations of the Authority in respect thereof within 15 (fifteen) Days from the date of the receipt of such DPR. In the event that the Independent Engineer and/or Authority has observed that the DPR is not in conformity with the Scope of Work, the Contractor shall promptly and without any undue delay revise and resubmit the DPR or satisfy the Independent Engineer and/or Authority with regards its compliance within 7 (seven) Days of receiving observations and suggestions from the Independent Engineer. If the Independent Engineer does not make any observation/comments with respect to the DPR submitted to it by the Contractor within 7 (seven) Days of the submission, it shall be deemed that the Independent Engineer has no suggestions to make with respect to the DPR and the Contractor shall be entitled to proceed with the Project accordingly. The Contractor shall not be entitled to any extension of time for completing implementation or any other relief on account of delay caused due to providing any clarification or in resubmitting the DPR. Provided, however, that the Authority at its sole discretion may suitably extend such time period or provide relief (excluding any liquidated damages or financial compensation paid by the Authority to the Contractor) to compensate for any such delay not attributable to the Contractor. The Contractor shall not change approved DPR under this Contract, without submitting such revised DPR for the review of the Independent Engineer/ Authority. Notwithstanding the review by the Independent Engineer, the Contractor shall be responsible for any defect and/or deficiency in the DPR relating to the Project or any part thereof, and accordingly, the Contractor shall at all times remain responsible for its obligations under this Contract. Within 90 (ninety) days of COD, the Contractor shall furnish to the Authority and the Independent Engineer a complete set of final survey charts as proof of satisfying the requirement of assured LAD for the entire stretch of the Project Site, in 2 (two) hard copies of and in its editable digital format or in such other medium and manner as may be acceptable to the Authority, reflecting the Project a...
Sample 1
Review of DPR. (i) The Concessionaire shall promptly and in such sequence as is consistent with the Construction Requirements, submit three copy of DPR to the Project Monitoring Consultant and CNP.
Sample 1

Related to Review of DPR

  • Review of Decision Within sixty (60) days after the Secretary’s receipt of a request for review, he or she will review the Company’s determination. After considering all materials presented by the Claimant, the Secretary will render a written opinion, written in a manner calculated to be understood by the Claimant, setting forth the specific reasons for the decision and containing specific references to the pertinent provisions of this Agreement on which the decision is based. If special circumstances require that the sixty (60) day time period be extended, the Secretary will so notify the Claimant and will render the decision as soon as possible, but no later than one hundred twenty (120) days after receipt of the request for review.

  • Review of Agreement Each party acknowledges that it has had time to review this agreement and, as desired, consult with counsel. In the interpretation of this agreement, no adverse presumption shall be made against any party on the basis that it has prepared, or participated in the preparation of, this agreement.

  • ADB’s Review of Procurement Decisions 11. All contracts procured under international competitive bidding procedures and contracts for consulting services shall be subject to prior review by ADB, unless otherwise agreed between the Borrower and ADB and set forth in the Procurement Plan. SCHEDULE 5 Execution of Project and Operation of Project Facilities; Financial Matters

  • Review of Documents Borrower has reviewed: (a) the Note, (b) the Security Instrument, (c) the Commitment Letter, and (d) all other Loan Documents.

  • Review of Materials During the term of this Agreement, Client shall ensure that all prospectuses, statements of additional information, registration statements, proxy statements, reports to shareholders, advertising and sales literature or other materials prepared for distribution to Fund shareholders or the public, which refer to the Subadviser in any way, prepared by employees or agents of Client or its affiliates are consistent with information previously provided by Subadviser. Subadviser shall promptly notify the Client of any changes to information pertaining to the Subadviser and stated in the materials described in this Section 6(g).

  • Review of Personnel File Upon written authority from an employee, OC shall permit the President of the Union or their designate to review that employee's personnel file in the office in which the file is normally kept in order to facilitate the proper investigation of a grievance.

  • Review of Personnel Files Every member shall be allowed to review any of his/her personnel files except "confidential law enforcement records" and "trial preparation records" as defined in Ohio Revised Code Section 149.43 at any time, upon request and reasonable notice. Such request shall be made to the supervisor directly responsible for maintenance of such files. Review of the files shall be made in the presence of such supervisor or the supervisor's designated representative. For the Division master personnel file, the request shall be made to the member's Subdivision Deputy Chief or his/her designated representative. Any member, or the member's Lodge representative, may copy documents in the member's file. The City may levy a charge for such copying, which charge shall bear a reasonable relationship to actual costs. A member will be notified in writing any time records within his/her personnel, background, IAB, and/or payroll file(s) are requested, as a public records request pursuant to Ohio Revised Code Section 149.43, provided the City determines that the request is proper under applicable law. A member may request copies of any records provided under this paragraph, and these copies shall be provided at no cost to the member.

  • REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The Contractor shall perform no portion of the Work at any time without Contract Documents or, where required, approved Shop Drawings, Product Data or Samples for such portion of the Work.

  • Periodic Review of Costs of Environmental Compliance In the ordinary course of its business, the Company conducts a periodic review of the effect of Environmental Laws on the business, operations and properties of the Company and its subsidiaries, in the course of which it identifies and evaluates associated costs and liabilities (including, without limitation, any capital or operating expenditures required for clean-up, closure of properties or compliance with Environmental Laws or any permit, license or approval, any related constraints on operating activities and any potential liabilities to third parties). On the basis of such review and the amount of its established reserves, the Company has reasonably concluded that such associated costs and liabilities would not, individually or in the aggregate, result in a Material Adverse Change.

  • Review Protocol A narrative description of how the Claims Review was conducted and what was evaluated.

Time is Money Join Law Insider Premium to draft better contracts faster.