The Independent Engineer Sample Clauses

The Independent Engineer. Concessioning Authority shall require the Concessionaire to carry out or cause to be carried out tests, at its own cost, to determine that such remedial measures have brought the Project into compliance with the Maintenance Requirements and the procedure set forth in this Clause 19.4 shall be repeated until the Project conforms to the Maintenance Requirements. In the event that remedial measures are not completed by the Concessionaire in conformity with the provisions of this Agreement, the Concessioning Authority shall be entitled to recover Damages from the Concessionaire under and in accordance with the provisions of Clause 17.8.
AutoNDA by SimpleDocs
The Independent Engineer. 14.6.1.1 shall not assign, transfer, mortgage or charge with an Encumbrance any right or obligation under this Agreement without the prior written consent of the PA Parties, which each of them may give or withhold in its absolute and unfettered discretion; and
The Independent Engineer. During commissioning, the Parties agree that the Independent Engineer shall have the right to review and comment on the test procedures and documents developed under this Schedule (Commissioning and Testing) to the extent necessary to enable the Independent Engineer to confirm the results of commissioning and otherwise to carry out the obligations and duties of the Independent Engineer.
The Independent Engineer. 17.1 The Independent Engineer shall be appointed by the Ministry of Economy on behalf of KOSTT in accordance with the relevant provisions of the Project Development Agreement.
The Independent Engineer. 2.1 The Independent Engineer's scope of work shall be as follows:
The Independent Engineer. 16.1 The Authority shall procure that the Independent Engineer shall monitor the progress of the Works and the Expansion Works upon the Site, and the Authority and the Contractor agree that the Independent Engineer shall be entitled to exercise rights, in accordance with the provisions of Schedule O. The Authority shall further require the Independent Engineer to inform the Authority of all matters of concern to the Independent Engineer which are likely to prevent or delay the Engineer's Declaration in accordance with Clause 28 (Engineer's Declaration) or the Further Engineer's Declaration in accordance with Clause 28A (Further Engineer's Declaration). The Independent Engineer shall have no authority to approve or accept the Contractor's performance of its obligations under the Contract as being satisfied or discharged except as provided in Clause 28 or Clause 28A. Save as otherwise agreed in writing by the Authority which agreement to be effective must refer to this Clause 16.1, notwithstanding the foregoing, the Authority shall inform the Contractor promptly of all matters of concern brought to the attention of the Authority by the Independent Engineer which are likely to prevent or delay the issue of the Engineer's Declaration in accordance with Clause 28 or the Further Engineer's Declaration in accordance with Clause 28A. Save as otherwise agreed in writing by the Authority which agreement to be effective must refer to this Clause 16.1, nothing done by the Authority or the Independent Engineer in accordance with this Clause 16 or Schedule O shall in any respect relieve or absolve the Contractor from its responsibility for the design of the Works and the Expansion Works or the provision of the Secure Training Centre and/or the Expansion Works under or in connection with the Contract.

Related to The Independent Engineer

  • Independent Engineer Contractor shall cooperate with Independent Engineer in the conduct of his or her duties in relation to the Project and the Work, including the duties listed in Attachment CC. No review, approval or disapproval by Independent Engineer shall serve to reduce or limit the liability of Contractor to Owner under this Agreement.

  • Geotechnical Engineer « »« » « » « » « » « »

  • Response/Compliance with Audit or Inspection Findings A. Grantee must act to ensure its and its Subcontractors’ compliance with all corrections necessary to address any finding of noncompliance with any law, regulation, audit requirement, or generally accepted accounting principle, or any other deficiency identified in any audit, review, or inspection of the Contract and the services and Deliverables provided. Any such correction will be at Grantee’s or its Subcontractor's sole expense. Whether Xxxxxxx's action corrects the noncompliance shall be solely the decision of the System Agency.

  • Appointment of Independent Engineer The Authority shall appoint a consulting engineering firm from a panel of 10 (ten) firms or bodies corporate, constituted by the Authority substantially in accordance with the selection criteria set forth in Schedule-P, to be the independent consultant under this Agreement (the “Independent Engineer”). The appointment shall be made no later than 90 (ninety) days from the date of this Agreement and shall be for a period of 3 (three) years. On expiry or termination of the aforesaid period, the Authority may in its discretion renew the appointment, or appoint another firm from a fresh panel constituted pursuant to Schedule-P to be the Independent Engineer for a term of 3 (three) years, and such procedure shall be repeated after expiry of each appointment.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Independent Review and Inspection The Owner may undertake independent inspection of the installation of the Work. Such independent inspector shall operate on behalf of the Owner and shall act to protect the best interests of the Owner.

  • Environmental Inspection at End of Agreement Term A. At Authority’s discretion, at least one hundred and twenty (120) days before the expiration or early termination of the Term as provided herein, Company will conduct an environmental inspection and examination of the Company Premises. At its discretion, Authority may complete environmental reviews to determine if recognized environmental conditions exist that could warrant soil and groundwater sampling. If warranted by the findings of Company or Authority’s inspection or if requested by Authority, a compliance audit or site assessment will be performed within the aforementioned time period by a qualified professional acceptable to Authority who will report the findings to Authority. The cost for professional consulting or engineering services required for such audit will be at the expense of Company. If a site assessment is conducted, Company agrees to pay all associated laboratory and testing fees incurred to test and analyze samples collected during the site assessment process. The Authority may also choose to conduct the compliance audit or site assessment. If the results of the assessment indicate that the Company Premises have been impacted by the release of Hazardous Substances, Company will immediately take such action as is necessary and will provide a substantial guaranty in a form and content acceptable to Authority that Company will clean up the contamination at its own expense, at no expense to Authority, and in accordance with Applicable Laws to the extent that it is obligated to do so by virtue of the foregoing provisions of this Article.

  • Office of Inspector General Investigative Findings Expert Review In accordance with Senate Bill 799, Acts 2021, 87th Leg., R.S., if Texas Government Code, Section 531.102(m-1)(2) is applicable to this Contract, Contractor affirms that it possesses the necessary occupational licenses and experience.

  • Environmental Audit Upon reasonable notice, Director shall have the right but not the obligation to conduct or cause to be conducted by a firm acceptable to Director, an environmental audit or any other appropriate investigation of the Premises for possible environmental contamination. Such investigation may include environmental sampling and equipment and facility testing, including the testing of secondary contamination. No such testing or investigation shall limit Tenant’s obligations hereunder or constitute a release of Tenant’s obligations therefor. Tenant shall pay all costs associated with said investigation in the event such investigation shall disclose any Hazardous Materials contamination as to which Tenant is liable hereunder.

  • Project Inspector 5.1.1 One or more Project Inspector(s), including special Project Inspector(s), as required, will be assigned to the Work by District, in accordance with requirements of title 24, part 1, of the California Code of Regulations, to enforce the building code and monitor compliance with Plans and Specifications for the Project previously approved by the DSA. Duties of Project Inspector(s) are specifically defined in section 4-342 of said part 1 of title 24.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!