Performance of Work, Governmental Permits and Insurance Sample Clauses

Performance of Work, Governmental Permits and Insurance. All of Tenant’s alterations and additions and installation of furnishings shall be coordinated with any work being performed by or for Landlord and in such manner as to maintain harmonious labor relations and not to damage the Office Area or Project or interfere with Office Area construction or operation and, except for installation of furnishings, shall be performed by Landlord’s general contractor or by contractors or workers first approved by Landlord. Except for work performed by Landlord’s general contractor, Tenant shall procure all necessary governmental permits before making any repairs, alterations, other improvements or installations. Except to the extent caused by the negligence or willful misconduct of Landlord or Landlord’s employees, agents or contractors, Tenant agrees to save harmless and indemnify Landlord from any and all injury, loss, claims or damage to any person or property occasioned by or arising out of the doing of any such work whether the same be performed prior to or during the Term of this Lease. With respect to alterations additions or improvements costing at least $250,000, at Landlord’s election, Tenant shall cause its contractor to maintain: (i) a payment and performance bond in such amount and with such companies as Landlord shall reasonably approve, and (ii) a xxxx xxxx, in recordable form, covering all work performed on the Premises; provided, however, the foregoing requirements shall not apply to Tenant’s Work. In addition, Tenant shall cause each contractor to carry insurance in accordance with Section 13.14 hereof and to deliver to Landlord certificates of all such insurance. Tenant shall also, with respect to (i) Tenant’s Work and (ii) future alterations, improvements or installations to the extent required for the type of work, prepare and submit to Landlord a set of as-built plans, in both print and electronic forms, showing such work performed by Tenant to the Premises promptly after any such alterations, improvements or installations are substantially complete and promptly after any wiring or cabling for Tenant’s computer, telephone and other communications systems is installed by Tenant or Tenant’s contractor. Without limiting any of Tenant’s obligations hereunder, Tenant shall be responsible, as Additional Rent, for the costs of any alterations, additions or improvements in or to the Office Area that are required in order to comply with Legal Requirements as a result of any work performed by Tenant. Landlord sh...
Sample 1Sample 2See All (25)
AutoNDA by SimpleDocs
Performance of Work, Governmental Permits and Insurance. All of Tenant's ------------------------------------------------------- alterations and additions and installation of furnishings, fixtures and equipment shall be coordinated with any work being performed by or for Landlord and in such manner as to maintain harmonious labor relations and not to damage the Building or Property or interfere with Building construction or operation and, except for installation of furnishings, shall be performed by Landlord's general contractor or by contractors or workmen first approved by Landlord, which approval shall not be unreasonably withheld. Except for work by Landlord's general contractor, Tenant shall procure all necessary governmental permits before making any repairs, alterations, other improvements or installations. Subject to Section 13.4, Tenant agrees to save harmless and indemnify Landlord from any and all injury, loss, claims or damage to any person or property occasioned by or arising out of the doing of any such work whether the same be performed prior to or during the Term of this Lease except to the extent caused by the negligence or willful misconduct of Landlord, its agents, contractors or employees. At Landlord's election, where the cost of such work exceeds $1,000,000.00 in any one instance, Tenant shall cause its contractor to maintain a payment bond in such amount and with such company as Landlord shall reasonably approve, and provided further that Landlord shall waive the requirement of obtaining a payment bond if Tenant demonstrates, to Landlord's reasonable satisfaction, that Tenant has funds or has obtained funding (or commitments for funding) sufficient to pay for the work in question. In addition, Tenant shall cause each contractor to carry worker's compensation insurance in statutory amounts covering the employees of all contractors and subcontractors, and commercial general liability insurance or comprehensive general liability insurance with a broad form comprehensive liability endorsement with such limits as Landlord may require reasonably from time to time during the Term of this Lease, but in no event less than such commercially reasonable amounts as may be reasonably required by Landlord, from time to time (all such insurance to be written in companies approved reasonably by Landlord and insuring Landlord, Landlord's managing agent and Tenant as additional insureds as well as contractors) and to deliver to Landlord certificates of all such insurance.
Sample 1
Performance of Work, Governmental Permits and Insurance. All of Tenant's alterations and additions and installation of furnishings shall be coordinated with any work being performed by or for Landlord and in such manner as to maintain harmonious labor relations and not to damage the Building or Site or interfere with Building construction or operation and, except for installation of furnishings, shall be performed by Landlord's general contractor or by contractors or workmen first approved by Landlord. Except for work by Landlord's general contractor, Tenant shall procure all necessary governmental permits before making any repairs, alterations, other improvements or installations. Tenant agrees to save harmless and indemnify Landlord from any and all injury, loss, claims or damage to any person or property occasioned by or arising out of the doing of any such work whether the same be performed prior to or during the Term of this Lease. In addition, Tenant shall cause each contractor to carry workmen's compensation insurance in statutory amounts covering the employees of all contractors and subcontractors, and commercial general liability insurance or comprehensive general liability insurance with a broad form comprehensive liability endorsement with such limits as Landlord may require reasonably from time to time during the Term of this Lease, but in no event less than the minimum amount of commercial general liability insurance or comprehensive general liability insurance Tenant is required to maintain as set forth in Section 1.2 hereof and as the same may be modified as provided in Section 13.2 hereof (all such insurance to be written in companies approved reasonably by Landlord and insuring Landlord, Landlord's managing agent and Tenant as well as contractors) and to deliver to Landlord certificates of all such insurance.
Sample 1
Performance of Work, Governmental Permits and Insurance. All of Tenant's alterations and additions and installation of furnishings shall be coordinated with any work being performed by or for Landlord and in such manner as to maintain harmonious labor relations and not to damage the Building or Site or interfere with Building construction or operation and, except for installation of furnishings, shall be performed by Landlord's general contractor or by contractors or workmen first approved by Landlord. Except for work by Landlord's general contractor, Tenant shall procure all necessary governmental permits before making any repairs, alterations, other
Sample 1

Related to Performance of Work, Governmental Permits and Insurance

  • COMPLIANCE WITH LAWS, LICENSES, PERMITS, AND INSURANCE POLICIES A. For each Term of this Agreement, Concessionaire shall obtain, pay for, maintain, and comply with all licenses, permits, certifications, authorizations, approvals, or any other documents required by all applicable government agency having jurisdiction over the Concession Premises or the conduct of Concessionaire's operations thereon. Concessionaire shall provide Department with written evidence that such applicable licenses, permits, authorizations, or other required documents have been obtained prior to commencement of the activity or operation covered by the license, permit, authorization, or other documentation. No operation shall begin until Concessionaire has provided such written evidence to Department.

  • Compliance with Laws; Governmental Authorizations 1.23.1 The Company is, and has at all times been, in compliance materially with all applicable Laws, except where non-compliance could not reasonably be expected to result in Material Adverse Effect. The Company has not received any notice or other communication from any Governmental Body or any other Person regarding (i) any actual, alleged, possible or potential material violation of, or failure to materially comply with, any Law; or (ii) any actual, alleged, possible or potential obligation on the part of the Company to undertake, or to bear all or any portion of the cost of, any cleanup or any remedial, corrective or response action of any nature under any applicable Law. The Company has provided to the Buyer a true, correct and complete copy of each report, study, survey or other document to which the Company has access that addresses or otherwise relates to the compliance of the Company with, or the applicability to the Company of, any Laws. To the knowledge of the Vendor, no Governmental Body has proposed or is considering any Law that, if adopted or otherwise put into effect, (A) may have an adverse effect on the business, condition, assets, liabilities, operations, financial performance, net income or prospects of the Company or on the ability of the Company to comply with or perform any covenant or obligation under any of ancillary documents contemplated by this Agreement; or (B) may have the effect of preventing, delaying, making illegal or otherwise interfering with the transactions contemplated by this Agreement.

  • No Conflicts; Governmental Approvals The execution, delivery and performance of the Agreement by the Company and the consummation by the Company of the transactions contemplated hereby do not and will not (i) violate any provision of the Company’s Articles of Incorporation or Bylaws, each as amended to date, (ii) conflict with, or constitute a default (or an event which with notice or lapse of time or both would become a default) under, or give to others any rights of termination, amendment, acceleration or cancellation of, any agreement, mortgage, deed of trust, indenture, note, bond, license, lease agreement, instrument or obligation to which the Company is a party or by which the Company’s properties or assets are bound, or (iii) result in a violation of any federal, state, local or foreign statute, rule, regulation, order, judgment or decree (including federal and state securities laws and regulations) applicable to the Company or by which any property or asset of the Company is bound or affected, except for such conflicts, defaults, terminations, amendments, acceleration, cancellations and violations as would not, individually or in the aggregate, have a Material Adverse Effect. The Company is not required under federal, state, foreign or local law, rule or regulation to obtain any consent, authorization or order of, or make any filing or registration with, any court or governmental agency in order for it to execute, deliver or perform any of its obligations under this Agreement or issue and sell the shares in accordance with the terms hereof (other than any filings, consents and approvals which may be required to be made by the Company under applicable state and federal securities laws, rules or regulations prior to or subsequent to the Closing).

  • Compliance with laws; payment of Permits/Licenses All services to be performed by Contractor pursuant to this Agreement shall be performed in accordance with all applicable Federal, State, County, and municipal laws, including, but not limited to, Health Insurance Portability and Accountability Act of 1996 (HIPAA) and all Federal regulations promulgated thereunder, as amended, and the Americans with Disabilities Act of 1990, as amended, and Section 504 of the Rehabilitation Act of 1973, as amended and attached hereto and incorporated by reference herein as Attachment “I,” which prohibits discrimination on the basis of handicap in programs and activities receiving any Federal or County financial assistance. Such services shall also be performed in accordance with all applicable ordinances and regulations, including, but not limited to, appropriate licensure, certification regulations, provisions pertaining to confidentiality of records, and applicable quality assurance regulations. In the event of a conflict between the terms of this agreement and State, Federal, County, or municipal law or regulations, the requirements of the applicable law will take precedence over the requirements set forth in this Agreement. Contractor will timely and accurately complete, sign, and submit all necessary documentation of compliance.

  • Governmental Permits, Etc The Company has all necessary franchises, licenses, certificates and other authorizations from any foreign, federal, state or local government or governmental agency, department or body that are currently necessary for the operation of the business of the Company as currently conducted, except where the failure to currently possess such franchises, licenses, certificates and other authorizations is not reasonably likely to have a Material Adverse Effect.

  • Compliance with Law; Governmental Approvals Each of the Borrower, the other Loan Parties and the other Subsidiaries is in compliance with each Governmental Approval and all other Applicable Laws relating to it except for noncompliances which, and Governmental Approvals the failure to possess which, could not, individually or in the aggregate, reasonably be expected to cause a Default or Event of Default or have a Material Adverse Effect.

  • Compliance with Laws, Contracts, Licenses, and Permits The Borrower and the Guarantors will, and will cause each of their respective Subsidiaries to, and, to the extent permitted by the terms of the Leases, will cause the Operators of the Pool Properties to, comply in all respects with (i) all Applicable Laws and regulations now or hereafter in effect wherever its business is conducted, including all Environmental Laws, (ii) the provisions of its corporate charter, partnership agreement, limited liability company agreement or declaration of trust, as the case may be, and other charter documents and bylaws, (iii) all agreements and instruments to which it is a party or by which it or any of its properties may be bound, (iv) all applicable decrees, orders, and judgments, and (v) all licenses and permits required Applicable Laws for the conduct of its business or the ownership, use or operation of its properties, except where failure so to comply with either clause (i) or (v) would not result in the material non-compliance with the items described in such clauses. If any authorization, consent, approval, permit or license from any officer, agency or instrumentality of any government shall become necessary or required in order that the Borrower, any Guarantor or their respective Subsidiaries may fulfill any of its obligations hereunder, the Borrower, such Guarantor or such Subsidiary will promptly take or cause to be taken all steps necessary to obtain such authorization, consent, approval, permit or license and furnish the Agent and the Lenders with evidence thereof. The Borrower shall develop and implement such programs, policies and procedures as are necessary to comply with the Patriot Act and shall promptly advise Agent in writing in the event that the Borrower shall determine that any investors in the Borrower are in violation of such act.

  • Permits and Compliance 12 Section 2.9

  • Governmental Permits and Approvals (a) All approvals, authorizations, consents, permits and licenses from governmental and regulatory bodies required for the transactions contemplated by this Agreement and to permit the business currently carried on by Earth to continue to be carried on substantially in the same manner immediately following the Closing Date shall have been obtained and shall be in full force and effect, and the Owners shall have been furnished with appropriate evidence, reasonably satisfactory to them, of the granting of such approvals, authorizations, consents, permits and licenses; and

  • Governmental Approvals; No Conflicts The execution, delivery and performance by the Borrower of this Agreement, and by each Loan Party of the other Loan Documents to which it is a party (a) do not require any consent or approval of, registration or filing with, or any action by, any Governmental Authority, except those as have been obtained or made and are in full force and effect, (b) will not violate any Requirements of Law applicable to the Borrower or any of its Subsidiaries or any judgment, order or ruling of any Governmental Authority, (c) will not violate or result in a default under any indenture, material agreement or other material instrument binding on the Borrower or any of its Subsidiaries or any of its assets or give rise to a right thereunder to require any payment to be made by the Borrower or any of its Subsidiaries and (d) will not result in the creation or imposition of any Lien on any asset of the Borrower or any of its Subsidiaries, except Liens (if any) created under the Loan Documents.

Time is Money Join Law Insider Premium to draft better contracts faster.