Notice to Offeror Sample Clauses

Notice to Offeror. Funds are not presently available for this effort. No award will be made under this solicitation until funds are available. The Government reserves the right to cancel this solicitation either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs. ITEM NO SUPPLIES/SERVICES MAX QUANTITY UNIT UNIT PRICE MAX AMOUNT 0001 UNDEFINED Lot LWP - NRE and Production Testing CPFF The contractor, as an independent contractor and not as an agent of the Government, shall provide engineering support to include Non-Recurring Engineering (NRE) and Production Testing as defined by requirements identified in the Statement of Objectives, Section L of this Request For Proposal (RFP), as well as in the Supplemental Specification/Requirements Package. FOB: Destination PSC CD: R425 MAX COST FIXED FEE TOTAL MAX COST + FEE ITEM NO SUPPLIES/SERVICES MAX QUANTITY UNIT UNIT PRICE MAX AMOUNT 0002 5 Each LWP Production Representative Units FFP The contractor shall provide up to five Production Representative Units, as defined by requirements identified in the Statement of Objectives, Section L of this Request For Proposal (RFP), as well as in the Supplemental Specification/Requirements Package Package. Unit Price per unit: $ FOB: Destination PSC CD: 1680 MAX NET AMT ITEM NO SUPPLIES/SERVICES MAX QUANTITY UNIT UNIT PRICE MAX AMOUNT 0003 1 Lot Lightweight Processor - Travel COST The Contractor shall support the LWP effort in accordance with the Statement of Objectives, Section L of this RFP. All travel must be approved by the COR prior to incurring any costs. All travel costs must be in accordance with the Joint Travel Regulations (JTR). This CLIN will be set-up as a Not-To-Exceed CLIN, under which the travel costs may not exceed the Not-To-Exceed Ceiling. FOB: Destination PSC CD: 1680 MAX COST ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT 0004 Over/Above -Technical Tasking Directives CPFF The Contractor shall furnish all labor, material, and facilities, except as otherwise specified herein, to provide engineering and technical service support for any above and beyond work issued to the Contractor as a Technical Tasking Directive. Reference Special H - Clause: Technical Tasking Directives. The Government reserves the right to exercise this option any time within the period of performance of the IDIQ. Orders may be placed at any time within the period of performance of this ...
Sample 1
AutoNDA by SimpleDocs
Notice to Offeror. The Government reserves the right to cancel this purchase request, either before or after suspense date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs. The contractor shall not request, nor will the Government make, payments for any preliminary measurement, quotes, bids, site visit, time or proposal cost incurred.
Sample 1
Notice to Offeror. Offeror are required to submit both Section B, Bid Schedule and Section J, Exhibit Line Items (ELINs) with their proposals. The total of the CLIN in Section B – Bid Schedule is equal to the sum of the ELINs in Section J as shown below: CLINs ELINs 0001 A001 through A004 0002 A700 through A709 0003 B001 through B004 0004 B700 through B709 0005 C001 through C004 0006 C700 through C709 0007 D001 through D004 0008 D700 through D709 0009 E001 through E004 0010 E700 through E709
Sample 1
Notice to Offeror. Upon the expiration of the Offering Period, the Offeror will advise the Offerees whether the Offer has been accepted in its entirety and if so, by whom.
Sample 1
Notice to Offeror. Due to increased security at all military installations, any Offeror who does not currently have a valid Contractor’s ID and Vehicle Decal issued by the Department of Defense (DoD), must allow sufficient time to obtain a one-day pass to permit entry to the base. In accordance with Naval Station security regulations all prospective visitors and contractor personnel are hereby notified that in order to obtain a one-day visitor’s pass the person must present their driver’s license and vehicle registration and/or rental car contract. Contractor personnel planning to hand deliver their proposals, who do not have a valid Contractor’s ID and a DoD decal on their vehicle, must submit a written request, fax a memorandum/letter, or send an e-mail, requesting a one-day pass to access the Naval Station. The written request shall include the company’s name, complete address, point of contact, phone number, fax number, e-mail address and the fill legal name of each representative needing access to the Naval Station for the purpose of submitting proposals for this solicitation. The request shall be sent to Xxxxxx Xxxxxx, Contract Specialist, via e-mail at xxxxxx.xxxxxx@xxxx.xxx five (5) business days prior to the date proposals are due. Personnel and vehicle one-day pass must be obtained at the Norfolk Naval Station Pass Office located on Hampton Boulevard down from Gate #5. It is imperative that offeror adhere to this notice in order to avoid delay in submitting your proposal. Also, be advised by this notice that the level of security at the Norfolk Naval Station may change at any time. As the level of security heightens, the amount of time required to gain access to the Naval Station also increases.
Sample 1

Related to Notice to Offeror

  • Notice to FINRA For a period of ninety (90) days after the date of the Prospectus, in the event any person or entity (regardless of any FINRA affiliation or association) is engaged, in writing, to assist the Company in its search for a Target Business or to provide any other services in connection therewith, the Company will provide the following to FINRA and the Representative prior to the consummation of the Business Combination: (i) complete details of all services and copies of agreements governing such services; and (ii) justification as to why the person or entity providing the merger and acquisition services should not be considered an “underwriter and related person” with respect to the Offering, as such term is defined in Rule 5110 of the FINRA Manual. The Company also agrees that, if required by law, proper disclosure of such arrangement or potential arrangement will be made in the tender offer documents or proxy statement which the Company will file with the Commission in connection with the Business Combination.

  • Notice to NASD In the event any person or entity (regardless of any NASD affiliation or association) is engaged to assist the Company in its search for a merger candidate or to provide any other merger and acquisition services, the Company will provide the following to the NASD and EBC prior to the consummation of the Business Combination: (i) complete details of all services and copies of agreements governing such services; and (ii) justification as to why the person or entity providing the merger and acquisition services should not be considered an "underwriter and related person" with respect to the Company's initial public offering, as such term is defined in Rule 2710 of the NASD's Conduct Rules. The Company also agrees that proper disclosure of such arrangement or potential arrangement will be made in the proxy statement which the Company will file for purposes of soliciting stockholder approval for the Business Combination.

  • NOTICE TO BIDDERS To ensure that your bid is responsive, you are urged to request clarification or guidance on any issues involving this solicitation before submission of your response. Your point-of-contact for this solicitation is Xxx Xxxxxxxxx, Contracting Agent at Xxx.Xxxxxxxxx@xxxx.xxx.

  • NOTICE TO BUYER Do not sign this agreement before you read it or if it contains any blank spaces. This is a legal instrument. All pages of this contract are binding. Read both sides of all pages before signing. You are entitled to an exact copy of the agreement, school catalog, and any other papers you may sign, and are required to sign a statement acknowledging receipt of those.

  • Notice to Holder Whenever the Exercise Price is adjusted pursuant to any provision of this Article 2, the Company shall promptly notify the Holder (by written notice) setting forth the Exercise Price after such adjustment and any resulting adjustment to the number of Warrant Shares and setting forth a brief statement of the facts requiring such adjustment.

  • Notice to Holders Where this Agreement provides for notice to Holders, such notice will be sufficiently given (unless otherwise herein expressly provided) if in writing and mailed, first-class postage prepaid, to each Holder affected by such event, at the Holder’s address as it appears in the CVR Register, not later than the latest date, and not earlier than the earliest date, if any, prescribed for the giving of such notice. In any case where notice to Holders is given by mail, neither the failure to mail such notice, nor any defect in any notice so mailed, to any particular Holder will affect the sufficiency of such notice with respect to other Holders.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Notice to Purchaser (1) DO NOT SIGN THIS CONTRACT UNTIL YOU READ IT OR IF IT CONTAINS BLANK SPACES.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

Time is Money Join Law Insider Premium to draft better contracts faster.