HINDRANCES AND DELAYS Sample Clauses

HINDRANCES AND DELAYS. No claims shall be made by Merchant for damages resulting from hindrances or delays from any cause during the progress of any portion of the work embraced in this Contract.
Sample 1
AutoNDA by SimpleDocs
HINDRANCES AND DELAYS. Subject to Sections 4.02 and Section 4.07, no Claim by Contractor will be allowed for damages resulting from hindrances or delays in the progress of any portion of the Work under any Task Order, regardless of the cause of any such delay. However, this provision does not apply where Engineer orders the Work stopped for reasons not attributable to Contractor.
Sample 1
HINDRANCES AND DELAYS. The Contractor expressly agrees that the construction period named in the Contract includes allowances for all hindrances and delays incident to the Work, including delays resulting from the need to re-do Work unacceptable to CPS Energy and caused by Contractor’s default. No claim shall be made by the Contractor for hindrances or delays from any cause during the progress of the Work, except as provided under Articles D.18, SUSPENSION OF WORK, and D.26, EXTENSIONS OF TIME.
Sample 1
HINDRANCES AND DELAYS. No charge shall be made by the Contractor for hindrances or delays from any cause during the progress of the work, or any portion thereof.
Sample 1
HINDRANCES AND DELAYS. Subject to Section 13 - Adjustment of Time for Completion and Section 18 - Extra Work the Contractor shall not have any claim for compensation for damages against the County for any stoppage or delay from any cause whatsoever.
Sample 1
HINDRANCES AND DELAYS. The Company shall not have any claim for compensation or damages against the City for any stoppage or delay from any cause whatsoever, whether such stoppage be caused by the action of the City or any other of its Contractors. No claim will be entertained for any stoppage or delay due to encountering of obstructions on the line of the Works that require adjustment, relocation or removal, whether or not such obstruction is shown on the plans or is apparent at the commencement of the Works. The City may stop any portion of the Work if, the weather is judged to prevent the same being properly done. No allowance of any kind will be made for such stoppage except an extension of the time for the completion of the Work hereafter provided.
Sample 1
HINDRANCES AND DELAYS. ‌ No claims shall be made by the Contractor for damages resulting from hindrances or delays from any cause (except where the Work is stopped by order of and for the convenience of the County) during the progress of any portion of the Work embraced in the Contract Documents. In case said work shall be stopped by the act of the County, then such expense, as in the sole judgment of the Observer is caused by such stoppage of said work, shall be paid by the County to the Contractor.
Sample 1
AutoNDA by SimpleDocs
HINDRANCES AND DELAYS. Except as provided herein, no charge shall be made by Contractor for hindrances or delays from any cause during the progress of any portion of the work set forth in this Contract; however, delays due to no fault or neglect of Contractor may entitle Contractor to a time extension sufficient to compensate for the delays. The amount of the time extension, if any, shall be determined by City Engineer provided Contractor gives City Engineer immediate notice in writing of the cause of such delay. The parties agree to negotiate in good faith for the recovery of damages related to expenses incurred by Contractor for a delay for which City is solely responsible that is unreasonable under the circumstances, and that was not within the contemplation of the parties to the Contract at the time the Contract was entered into.
Sample 1

Related to HINDRANCES AND DELAYS

  • Permitted Delays The Company shall be entitled to postpone the filing of any Registration Statement under Section 2.3 if (i) at any time prior to the filing of such Registration Statement the Board of Directors of the Company determines, in its good faith business judgment, that such registration and offering would materially and adversely affect any financing, acquisition, corporate reorganization or other material transaction involving the Company, and (ii) the Company delivers the Holders requesting such registration written notice thereof within 10 business days of the date of receipt of such request; provided, that all such periods of postponement may not exceed 45 days during any 365-day period.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Powers and Remedies Cumulative; Delay or Omission Not Waiver of Default Except as provided in Section 5.6, no right or remedy herein conferred upon or reserved to the Trustee or to the Holders of Securities or Coupons is intended to be exclusive of any other right or remedy, and every right and remedy shall, to the extent permitted by law, be cumulative and in addition to every other right and remedy given hereunder or now or hereafter existing at law or in equity or otherwise. The assertion or employment of any right or remedy hereunder, or otherwise, shall not prevent the concurrent assertion or employment of any other appropriate right or remedy. No delay or omission of the Trustee or of any Holder of Securities or Coupons to exercise any right or power accruing upon any Event of Default occurring and continuing as aforesaid shall impair any such right or power or shall be construed to be a waiver of any such Event of Default or an acquiescence therein; and, subject to Section 5.6, every power and remedy given by this Indenture or by law to the Trustee or to the Holders of Securities or Coupons may be exercised from time to time, and as often as shall be deemed expedient, by the Trustee or by the Holders of Securities or Coupons.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

Time is Money Join Law Insider Premium to draft better contracts faster.