Extensions of Time Sample Clauses

Extensions of Time. 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
AutoNDA by SimpleDocs
Extensions of Time. The Parties reserve the right, by agreement and subject to the Court’s approval, to grant any reasonable extension of time that might be needed to carry out any of the provisions of this Agreement.
Extensions of Time. 4.5.1 In the event that the SPD is prevented from performing its obligations under Article
Extensions of Time. The Developer may be allowed extensions of time for commencement of construction, or for beyond the completion date, for unavoidable delays such as those caused by strikes, lockouts, acts of God, or factors beyond the control of the Developer. Application for extension shall be made on the Teton County “Development Agreement Extension Application” and shall address the criteria presented on that form and in Exhibit C, Extension Criteria. The Developer shall pay the fee associated with the request. Developer acknowledges and agrees that the Board of County Commissioners has the sole discretion to grant or deny a request for extension. The application for a development agreement extension must be submitted to the Planning Department before the expiration of the original development agreement.
Extensions of Time. The Settling Parties may agree upon a reasonable extension of time for deadlines and dates reflected in this Settlement Agreement, without further notice (subject to Court approval as to Court dates).
Extensions of Time. The time limitations specified for either the grievant or the College may be extended by written mutual agreement. Such extension of time on the part of the College Area must be approved by the Director of Labor Relations/General Counsel, or his designee, for STEPS ONE through THREE.
Extensions of Time. Any time limit set forth in these Rules may be extended upon agreement of the parties and approval of: (i) the Chairman of the Mediation Committee if the proceeding is then in Mediation; (ii) the Administrator if the proceeding is in Arbitration, but no Arbitration Panel has been selected; or (iii) the Arbitration Panel, if the proceeding is in Arbitration and the Arbitration Panel has been selected.
AutoNDA by SimpleDocs
Extensions of Time. Consultant may, for good cause, request extensions of time to perform the services required hereunder. Such extensions shall be authorized in advance by the City in writing and shall be incorporated in written amendments to this Contract or the attached work program.
Extensions of Time. Applications for extensions of time shall be made on the Teton County “Development Agreement Extension Application” attached hereto as Exhibit D and shall address the criteria presented on that form. The Developer shall pay the fee associated with the request. Developer acknowledges and agrees the Board of County Commissioners has the sole discretion to grant or deny a request for extension. Any application for an extension of time must be submitted to the Planning Department before the expiration of the original deadline.
Extensions of Time. 24.1 Company may reasonably request an extension to the schedule for changes in the Project, as contemplated by Article 4.0, and for events of Force Majeure, as provided in Article 23.0.
Time is Money Join Law Insider Premium to draft better contracts faster.