Failure to Meet Contract Requirements Sample Clauses

Failure to Meet Contract Requirements. The MCO must comply with all requirements and performance standards set forth in this Contract. The MCO agrees that failure to comply with all provisions of the Contract may result in the assessment of remedies and/or termination of the Contract, in whole or in part, in accordance with this Article. The MCO agrees and understands that the Department may pursue contractual remedies for non-performance under the Contract. At any time and at its discretion, the Department may impose or pursue one or more remedies for each item of non-performance and will determine remedies on a case-by-case basis. The Department is entitled to monetary damages in the form of actual, consequential, direct, indirect, special, and/or Liquidated Damages resulting from the MCO’s non-performance under this Contract. In some cases, the actual damage to the Department as a result of the MCO’s failure to meet any aspect of the responsibilities of the Contract and/or to meet specific performance standards set forth in the Contract will be difficult or impossible to determine with precise accuracy. Therefore, in the event of non-performance under this Contract, the Department will impose Liquidated Damages in writing against the MCO. In the event of non- performance the Department will assess Liquidated Damages against the MCO regardless of whether the non- performance is the fault of the MCO (including the MCO's Subcontractors, agents and/or consultants), provided the Department has not materially caused or contributed to the non-performance. The Liquidated Damages prescribed in this Contract are not intended to be in the nature of a penalty, but are intended to be reasonable estimates of the Department’s projected financial loss and damage resulting from the MCO’s non-performance. Accordingly, in the event the MCO fails to perform in accordance with the Contract, the Department may assess Liquidated Damages as provided in this Section and in Appendix G of this Contract. Monetary penalties imposed under this Contract will not exceed the amounts established under 42 CFR §438.704. Any Liquidated Damages assessed by the Department will be due and payable within thirty (30) calendar days after the MCO’s receipt of the notice of damages, regardless of any dispute in the amount or interpretation which led to the notice, or an appeal of the notice filed by the MCO. If MCO fails to pay assessed damages within thirty (30) calendar days, the amount of damages will be deducted against capitation ...
AutoNDA by SimpleDocs
Failure to Meet Contract Requirements. The MCO must comply with all requirements and performance standards set forth in this Contract. The MCO agrees that failure to comply with all provisions of the Contract may result in the assessment of remedies and/or termination of the Contract, in whole or in part, in accordance with this Article. The MCO agrees and understands that BMS may pursue contractual remedies for non-performance under the Contract. At any time and at its discretion, BMS may impose or pursue one (1) or more remedies for each item of non-performance and will determine remedies on a case-by-case basis. BMS is entitled to monetary damages in the form of actual, consequential, direct, indirect, special, and/or Liquidated Damages resulting from the MCO’s non-performance under this Contract. In some cases, the actual damage to BMS as a result of the MCO’s failure to meet any aspect of the responsibilities of the Contract and/or to meet specific performance standards set forth in the Contract will be difficult or impossible to determine with precise accuracy.
Failure to Meet Contract Requirements. ‌ The DB Contractor understands and agrees that if the DB Contractor fails to complete the Work in accordance with the Contract Documents, the District will suffer substantial losses and damages. The DB Contractor agrees that it shall be liable for all such losses and damages. The DB Contractor acknowledges and agrees that because of the unique nature of the Project, the fact that it is an essential part of the St Elizabeths East Campus Project, and the fact that inconvenience to the local and regional traffic, especially commuters entering or leaving Washington, DC, will be one of the significant impacts of any completion delay, it is impracticable and extremely difficult to ascertain and calculate the actual damages which would accrue to the District and the public in the event of the DB Contractor’s failure to achieve Substantial Completion and Final Completion by the applicable Project Completion Dates.
Failure to Meet Contract Requirements. When the Contractor fails to meet the requirements of the Contract, the product or service may be brought from any source by City, and if a greater price than that named in the Contract is paid by City, the excess price will be charged to and collected from the Contractor.
Failure to Meet Contract Requirements. ADRCs which fail to meet the provisions of this contract shall be subject to a sequential process that may include development of a plan of correction, fiscal or non-fiscal enforcement measures, or contract termination, as determined by the Department.

Related to Failure to Meet Contract Requirements

  • CONTRACT REQUIREMENTS a. NSF will exercise its responsibility for oversight and monitoring of procurements, contracts or other contractual arrangements for the purchase of materials and supplies, equipment or general support services under the award. The procedures set forth below must be followed to ensure that performance, materials and services are obtained in an effective manner and in compliance with the provisions of applicable Federal statutes and executive orders. The awardee must obtain written approval from the cognizant NSF Grants and Agreements Officer prior to entering into a contract if the amount exceeds $250,000 or other amount specifically identified in the agreement. Contracts clearly identified in the NSF award budget are considered approved at the time of award unless approval is withheld by the Grants and Agreements Officer. Contracts must be clearly identified in the NSF award budget on Line G6. Other. The threshold noted above also applies to cumulative increases in the value of the contractual arrangement after initial NSF approval. The awardee must not artificially segregate its procurements to lesser dollar amounts for the purpose of circumventing this requirement. A request to enter into a contract must include, at a minimum:

  • Subcontract Requirements As required by Section 6.22(e)(5) of the Administrative Code, Contractor shall insert in every subcontract or other arrangement, which it may make for the performance of Covered Services under this Agreement, a provision that said subcontractor shall pay to all persons performing labor in connection with Covered Services under said subcontract or other arrangement not less than the highest general prevailing rate of wages as fixed and determined by the Board of Supervisors for such labor or services.

  • SPECIAL CONTRACT REQUIREMENTS The Special Contract Requirements are provisions that relate directly to the performance of this contract.

  • Report Requirements The Company will send to the Reinsurer the following reports electronically, by the times indicated below:

  • Export Requirements The Program, Documentation and all related technical information or materials are subject to export controls and U.S. Government export regulations. You will comply strictly with all legal requirements established under these controls and will not, in connection with its limited evaluation rights hereunder, export, re-export, divert, transfer or disclose, directly or indirectly the Program, Documentation and any related technical information or materials without the prior approval of the U.S.

  • Compliance with Xxxxxxxx Act requirements The contractor shall comply with the requirements of 29 CFR part 3, which are incorporated by reference in this contract.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Support Requirements If there is a dispute between the awarded vendor and TIPS Member, TIPS or its representatives may assist, at TIPS sole discretion, in conflict resolution or third party (mandatory mediation), if requested by either party. TIPS, or its representatives, reserves the right to inspect any project and audit the awarded vendors TIPS project files, documentation and correspondence. Status of TIPS Members as Related to This Agreement TIPS Members stand in the place of TIPS as related to this agreement and have the same access to the proposal information and all related documents. TIPS Members have all the same rights under the awarded Agreement as TIPS.

  • Data Requirements ‌ • The data referred to in this document are encounter data – a record of health care services, health conditions and products delivered for Massachusetts Medicaid managed care beneficiaries. An encounter is defined as a visit with a unique set of services/procedures performed for an eligible recipient. Each service should be documented on a separate encounter claim detail line completed with all the data elements including date of service, revenue and/or procedure code and/or NDC number, units, and MCE payments/cost of care for a service or product. • All encounter claim information must be for the member identified on the claim by Medicaid ID. Claims must not be submitted with another member’s identification (e.g., xxxxxxx claims must not be submitted under the Mom’s ID). • All claims should reflect the final status of the claim on the date it is pulled from the MCE’s Data Warehouse. • For MassHealth, only the latest version of the claim line submitted to MassHealth is “active”. Previously submitted versions of claim lines get offset (no longer “active” with MassHealth) and payments are not netted. • An encounter is a fully adjudicated service (with all associated claim lines) where the MCE incurred the cost either through direct payment or sub-contracted payment. Generally, at least one line would be adjudicated as “paid”. All adjudicated claims must have a complete set of billing codes. There may also be fully adjudicated claims where the MCE did not incur a cost but would otherwise like to inform MassHealth of covered services provided to Enrollees/Members, such as for quality measure reporting (e.g., CPT category 2 codes for A1c lab tests and care/patient management). • All claim lines should be submitted for each Paid claim, including zero paid claim lines (e.g., bundled services paid at an encounter level and patient copays that exceeded the fee schedule). Denied lines should not be included in the Paid submission. Submit one encounter record/claim line for each service performed (i.e., if a claim consisted of five services or products, each service should have a separate encounter record). Pursuant to contract, an encounter record must be submitted for all covered services provided to all enrollees. Payment amounts must be greater than or equal to zero. There should not be negative payments, including on voided claim lines. • Records/services of the same encounter claim must be submitted with same claim number. There should not be more than one active claim number for the same encounter. All paid claim lines within an encounter must share the same active claim number. If there is a replacement claim with a new version of the claim number, all former claim lines must be replaced by the new claim number or be voided. The claim number, which creates the encounter, and all replacement encounters must retain the same billing provider ID or be completely voided. • Plans are expected to use current MassHealth MCE enrollment assignments to attribute Members to the MassHealth assigned MCE. The integrity of the family of claims should be maintained when submitting claims for multiple MCEs (ACOs/MCO). Entity PIDSL, New Member ID, and the claim number should be consistent across all lines of the same claim. • Data should conform to the Record Layout specified in Section 3.0 of this document. Any deviations from this format will result in claim line or file rejections. Each row in a submitted file should have a unique Claim Number + Suffix combination. • A feed should consist of new (Original) claims, Amendments, Replacements (a.k.a. Adjustments) and/or Voids. The replacements and voids should have a former claim number and former suffix to associate them with the claim + suffix they are voiding or replacing. See Section 2.0, Data Element Clarifications, for more information. • While processing a submission, MassHealth scans the files for the errors. Rejected records are sent back to the MCEs in error reports in a format of the input files with two additional columns to indicate an error code and the field with the error. • Unless otherwise directed or allowed by XxxxXxxxxx, all routine monthly encounter submissions must be successfully loaded to the MH DW on or before the last day of each month with corrected rejections successfully loaded within 5 business days of the subsequent month for that routine monthly encounter submission to be considered timely and included in downstream MassHealth processes. Routine monthly encounter submissions should contain claims with paid/transaction dates through the end of the previous month.

  • CONTRACT COMPLIANCE REQUIREMENT The HUB requirement on this Contract is 0%. The student engagement requirement of this Contract is 0 hours. The Career Education requirement for this Contract is 0 hours. Failure to achieve these requirements may result in the application of some or all of the sanctions set forth in Administrative Policy 3.10, which is hereby incorporated by reference.

Time is Money Join Law Insider Premium to draft better contracts faster.