Target Schedule definition

Target Schedule means a copy of the schedule where dates are frozen and those dates are not allowed to be modified by progress reporting, schedule changes, or further recalculations. Target Schedules take current schedule information which is dynamic and establishes static schedule data for comparison purposes. A project can have multiple Target Schedules (i.e. - copies of the schedule made at different times during project execution). The Original Schedule is usually the first Target Schedule to be generated within a project.
Sample 1Sample 2
Target Schedule is defined in the preamble to Article V hereof.
Sample 1
Target Schedule means a copy of the schedule where dates are frozen and those dates are not allowed to be modified by progress reporting, schedule changes, or further recalculations. Target Schedules take current schedule
Sample 1

Examples of Target Schedule in a sentence

  • However, such revisions or revised schedule shall not change or modify the Project Duration set forth in the Target Schedule or Book 1.

  • The Proposed Target Schedule and the Target Schedule must be provided in hard copy and editable electronic format.

  • If the Contractor, in the judgment of the Commission, is failing to meet the Target Schedule, including any Contract milestones, the Contractor, upon the written request of the Commission Representative, shall submit a recovery schedule.

  • The Contractor must maintain an adequate work force and the necessary materials, supplies and equipment to meet the Target Schedule.

  • The Commission Representative may direct the Contractor to revise the Target Schedule.

  • The Commission Representative will direct the Contractor to provide a revised Target Schedule in writing.

  • Upon approval, the revision to the Target Schedule or revised Target Schedule shall be designated the new Target Schedule.

  • Specifically demonstrate the negative impact of the delay on the critical path of the Target Schedule by submitting a complete Time Impact Analysis (TIA) which shall include a fragmentary critical path network (Fragnet) that accounts for any float on the project and illustrates the impact of the alleged delay on the Target Schedule.

  • The Target Schedule shall be submitted and approved as provided herein and shall serve as the schedule for the Project.

  • Upon receipt of the Proposed Target Schedule and later the Target Schedule, the Commission will review each Schedule for conformance with the Contract Documents and degree of detail.


More Definitions of Target Schedule

Target Schedule means the target completion schedule produced by the EPCM Contractor as part of the Phase I EPCM Work and set forth in Appendix 3 to Schedule 2, as the same may be modified from time to time in accordance with this Agreement.
Sample 1
Target Schedule means the general construction schedule for Landlord’s Work which is attached as Exhibit D-2, initialed by each of Landlord and Tenant, dated as of October 13, 2011, and made a part hereof.
Sample 1
Target Schedule. County has suggested October 31, 2013 as a goal for concluding negotiations, SOI amendment, development plan, design guidelines, and development agreement. Process: verbiage will be needed to provide the City with comfort that their input will be sought and considered as the development plan and design guidelines are prepared.
Sample 1

Related to Target Schedule

  • Shift Schedule means a projection of Employees’ shifts with regard to days worked and days off, including shift starting and terminating times.

  • Product Schedule means PTC’s standard order form entitled “PTC Product Schedule” (including all schedules, attachments and other document(s) specifically referenced therein) or such alternative order form as may be submitted by Customer and accepted by PTC, in each case that specifies (i) the Licensed Products and/or Services ordered; and (ii) for Licensed Products, the installation address (including the Designated Country) and the Licence Term.

  • Specification Schedule means the Schedule containing details of the Specification.

  • Contract Schedule means a schedule to this Contract;

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Progress Schedule means a schedule of the Work, in a form satisfactory to Owner, as further set forth in Section 3.02.

  • Asset Schedule means with respect to any Transaction as of any date, an asset schedule in the form of a computer tape or other electronic medium (including an Excel spreadsheet) generated by Seller and delivered to Buyer and the Custodian, which provides information (including, without limitation, the information set forth on Exhibit E attached hereto) relating to the Purchased Mortgage Loans in a format reasonably acceptable to Buyer.

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Development Schedule shall have the meaning set forth in Section 1.1.

  • Time Schedule means the Time Schedule for final completion of the Works or Mechanical Completion of the Plant(s)/Unit(s) as the case may be, incorporated in the Contract or as may be extended by the OWNER or Engineer-in-Charge pursuant to the provisions hereof and shall include interim time schedules set up for achieving interim/phase-wise/stage-wise progress/completion/testing/commissioning/handing over, as may be prescribed by the OWNER/Engineer-in-Charge, within the overall Time Schedule as originally envisaged or as extended.

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Delivery Schedule means the schedule for the delivery of Services as set forth in attached Annex 3.

  • Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • TARGET 2 means the Trans-European Automated Real-time Gross Settlement Express Transfer payment system which utilises a single shared platform and which was launched on 19 November 2007.

  • Payment Schedule ’ means a schedule which sets out—

  • Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.

  • Equipment Schedule means (a) each Equipment Schedule attached to the applicable Requisition and (b) each Equipment Schedule attached to the applicable Lease Supplement.

  • Order Schedule means an MSC Order Schedule (or other order document) agreed to by Customer and MSC, and which incorporates this Agreement, by reference or otherwise, and sets forth, among other things, the Software, Maintenance and/or Services ordered.

  • Rent Schedule means a written schedule for the Mortgaged Property showing the name of each tenant, and for each tenant, the space occupied, the lease expiration date, the rent payable for the current month, the date through which rent has been paid, and any related information requested by Lender.

  • Purchase Price Allocation Schedule has the meaning set forth in Section 5.11(f)(ii).

  • Schedule means a schedule to this Agreement.

  • Allocation Schedule has the meaning set forth in Section 2.07.

  • Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.

  • Tariff Schedule means the tariff schedule contained in Annexure B to this Access Arrangement or, if Envestra has published a revised tariff schedule, the tariff schedule in effect from time to time.