Examples of Practical Completion in a sentence
Any dispute as to whether or not Practical Completion has taken place will be referred to adjudication in accordance with clause 13.
Following notification by the Contractor to the Employer of the Contractor’s desire to hand over the Works to the Employer on Practical Completion the Employer shall within 10 Working Days of such notification procure that the Contract Administrator shall inspect the Works and if in the Contract Administrator is of the reasonable opinion that Practical Completion has taken place the Contract Administrator will issue the Practical Completion Statement.
The Contractor shall not less than [2] weeks prior to the anticipated Practical Completion Date, give written notice to the Contract Administrator of the date the Contractor expects Practical Completion to take place.
Appropriate signage should be displayed ensuring visibility from main access routes, and fencing should be erected on the perimeter of the Works being undertaken, which will be removed on the Practical Completion Date only after receipt of the Independent Inspection and approval by The Employer or Contracts Administrator.