Snagging Items Sample Clauses

POPULAR SAMPLE Copied 41 times
Snagging Items. In the event that a Certificate of Availability for a Phase is expected to be subject to Snagging Items: 20.7.1 the Independent Certifier shall within five (5) Business Days of the issue of the relevant Certificate of Availability issue to the Contractor and the Authority a list of the relevant snagging items for that Phase (the Snagging List). Within five (5) Business Days of receipt from the Independent Certifier of the Snagging List the Contractor shall provide to the Authority and the Independent Certifier a reasonable programme for making good each Snagging Item set out in the Snagging List provided that such programme shall require that each Snagging Item shall be made good within one twenty (20) Business Days of the date of the agreement or determination of that programme or within such time as is reasonably practicable. The parties shall seek to agree such programme and in default of agreement shall refer the matter for determination under the Dispute Resolution Procedure. The programme agreed or determined in accordance with this clause 20.7.1 (Snagging Items) shall be known as the Snagging Programme; and 20.7.2 the Contractor shall procure that each Snagging Item is made good in accordance with the Snagging Programme to the satisfaction of the Independent Certifier. If any Snagging Item has not been rectified by the date set out in the Snagging Programme then the Authority shall be entitled to effect such repairs as may be necessary and recover the costs of doing so from the Contractor.
View SourceView Similar (5)
Snagging Items. Landlord shall cause correction and completion of all snagging items and shall provide periodic progress updates regarding the completion of such snagging items to Tenant. Failure to include any snagging item in the Shell Building Works Certificate of Practical Completion will not alter the responsibility of Landlord for completion of all Shell Building Works and Stage Works. If any snagging item must be completed after commencement by Tenant of Tenant's installations (as provided for in each Lease), Landlord shall coordinate with Tenant and Tenant's contractor to ensure timely completion of the snagging items and mitigate any unreasonable disruption to Tenant's installations and Tenant's construction schedule. The terms and provisions of this Clause 11.5 shall survive the expiration of this Agreement.
View SourceView Similar (2)
Snagging Items. The Developer shall, as soon as reasonably practicable after Base Building Works Practical Completion remedy or cause to be remedied the Snagging Items
View Source
Snagging Items. The Property shall be deemed to have been completed on the issue by the Employer’s Agent of the Practical Completion Certificate notwithstanding that any Snagging Items appear in any Snagging List and are to be corrected or completed by the Building Contractor after completion of the sale.
View Source
Snagging Items. The Independent Tester shall on the same day as the date of issue of the Permit to Use in relation to a [Phase] [the Works] issue to Project Co. and the Authority a list of the relevant Snagging Items (the "Snagging List"). Within [five (5)] Business Days after the date of receipt from the Independent Tester of the Snagging List, Project Co will provide to the Authority and the Independent Tester a reasonable programme (the "Snagging Programme") for making good each Snagging Item set out in the Snagging List provided that the Snagging Programme will require that each Snagging Item will be made good within twenty
View Source
Snagging Items. (a) On the date of issuing the Permit to Use, Project Co shall enforce its contractual rights to procure that the Independent Certifier will issue a complete list of all Snagging Items (the "Snagging List") to TfL and Project Co. (b) Within ten (10) Working Days of receipt by Project Co of the Snagging List, Project Co shall provide to TfL and the Independent Certifier for their agreement a reasonable programme for making good each Snagging Item, which programme shall require that each Snagging Item shall be made good as soon as reasonably practicable, and in any event within three (3) months after the Permit to Use Date other than: (i) any landscaping Snagging Items that cannot be completed within such three (3) month period for seasonal reasons, in which case completion shall be as soon as reasonably practicable; or (ii) any other Snagging Items which Project Co can demonstrate to TfL's reasonable satisfaction cannot be completed within such three (3) month period, in which case completion shall be by a date to be agreed with TfL (acting reasonably). (c) Within ten (10) Working Days of receipt of the programme under clause 18.3(b) or clause 18.3(d) (as applicable), Project Co shall enforce its contractual rights to procure that the Independent Certifier (acting reasonably) either: (i) notifies Project Co that the proposed programme is accepted; or (ii) provides comments on the proposed programme. (d) Project Co shall take into account any reasonable comments raised by the Independent Certifier pursuant to clause 18.3(c)(ii) in relation to the proposed programme and provide the revised programme to TfL and the Independent Certifier for review and the provisions of clause 18.3(c) and this clause 18.3(d) shall thereafter apply to such programme mutatis mutandis. (e) The programme accepted by the Independent Certifier under clause 18.3(c)(i) (or otherwise determined in accordance with the Dispute Resolution Procedure) shall be known as the "Snagging Programme". (f) Project Co shall ensure that making good of the Snagging Items shall not interfere with: (i) the use of the Project Roads by Users and the use of the TLRN, the SRN and other roads by the public; or (ii) the carrying out of the Services. (g) Project Co: (i) shall ensure that each Snagging Item is made good in accordance with the Snagging Programme; (ii) acknowledges and agrees that Project Co shall be responsible for obtaining any required access to the relevant area for the purpose of making good ...
View Source
Snagging Items. The Independent Tester may issue a Certificate of Service Availability for a [Project Facility] subject to Snagging Items in accordance with the following provisions: (a) The Independent Tester will on the same day as the date of issue of a relevant Certificate of Service Availability issue to PPP Co. and the Authority a list of the relevant Snagging Items for that [Project Facility] (the “Snagging List”). Within five (5) Business Days after the date of receipt from the Independent Tester of the Snagging List, PPP Co. will provide to the Authority and the Independent Tester a reasonable programme (the “Snagging Programme”) for making good each Snagging Item set out in the Snagging List. The Snagging Programme will require that each Snagging Item will be made good within twenty (20) Business Days after the date of provision of the Snagging Programme or within such time as is reasonably practicable. The Parties will seek to agree the Snagging Programme or in default of agreement will refer the matter for determination under Clause 45 (Dispute Resolution Procedure). Pending any such referral or the outcome of any referral, PPP Co. shall be required to proceed with the making good of Snagging Items in accordance with the Snagging Programme. (b) PPP Co. will make good each Snagging Item in accordance with the Snagging Programme to the satisfaction of the Independent Tester. Upon satisfactory completion of the Snagging List the Independent Tester will issue the Snagging Items Completion Certificate for the relevant Project Facility in accordance with the Independent Tester Contract and Schedule 6 (Certification Procedure). If any Snagging Item has not been rectified by the date set out in the Snagging Programme then the Authority will be entitled either: (i) to effect such repairs as may be necessary and recover the costs of effecting such repairs from PPP Co. as a debt; or (ii) to report the Snagging Item to the helpdesk to be managed in accordance with the relevant helpdesk provisions set out in Schedule 10 (Services Requirements). (c) PPP Co. shall agree a programme with the Authority for making good Snagging Items, having regard to the reasonable use of the [Project Facilities] and in order to minimise disruption to Users and the Parties shall take into account any such period of use in agreeing and implementing the Snagging Programme.
View Source
Snagging Items. The Developer shall, as soon as reasonably practicable after Developer’s Works Practical Completion in respect of the relevant Office Floor remedy or cause to be remedied the Snagging Items at the sole cost of the Developer
View Source

Related to Snagging Items

  • Post-Closing Items (a) The Loan Parties shall take all necessary actions to satisfy the items described on Schedule 5.16 within the applicable periods of time specified in such Schedule (or such longer periods as the Administrative Agent may agree in its sole discretion). (b) In connection with each of the Mortgaged Properties, within ninety (90) days of the Closing Date (or such longer period as the Administrative Agent may reasonably allow) (i) each of the Mortgages, in form and substance reasonably satisfactory to the Administrative Agent, relating to each of the Mortgaged Properties shall have been duly executed by the parties thereto and delivered to the Collateral Agent and shall be in full force and effect; except for the Deed of Mortgage, which the Loan Parties represent has been filed and recorded in the corresponding Section of the Puerto Rico Registry of Property and the Deed of Amendment, which the Loan Parties represent has been filed and is pending recordation in the corresponding Section of the Puerto Rico Registry of Property, (ii) each of such Mortgaged Properties shall not be subject to any Lien other than those permitted under Section 6.02 and (iii) (A) each of such Mortgages shall have been filed and recorded in the corresponding recording office (except for the Deed of Mortgage, which the Loan Parties represent has been filed and recorded in the corresponding Section of the Puerto Rico Registry of Property and the Deed of Amendment which the Loan Parties represent has been filed and is pending recordation in the corresponding Section of the Puerto Rico Registry of Property) and, in connection therewith, the Collateral Agent shall have received evidence reasonably satisfactory to it of each such filing and recordation and (B) the Collateral Agent shall have received such other documents, including a policy or policies of title insurance issued by a nationally recognized title insurance company in an amount not to exceed the fair market value of such mortgaged property (as determined in good faith by the Lead Borrower), together with such endorsements, coinsurance and reinsurance as may be reasonably requested by the Collateral Agent and the Lenders, insuring the Mortgages as valid first liens on the Mortgaged Properties, free of Liens other than those permitted under Section 6.02, together with such flood determinations, surveys and legal opinions required to be furnished pursuant to the terms of the Mortgages or as reasonably requested by the Collateral Agent or the Administrative Agent.

  • Electrical Items All electrical items purchased under this Grant Agreement/Contract or used in the performance of approved and eligible grant-funded activities must meet all applicable Occupational Safety and Health Administration (OSHA) standards and regulations, and bear the appropriate listing from Underwriters Laboratory (UL), Factory Mutual Resource Corporation (FMRC), or National Electrical Manufacturers Association (NEMA).

  • Other Items Any other items that the Bank reasonably requires.

  • Compressed Work Week The Company and Union recognize the concept of the compressed work week. It is further understood that the compressed work week conditions will apply only to those departments that are on the compressed work week.

  • Collection of Taxes, Assessments and Similar Items; Escrow Accounts (a) To the extent required by the related Mortgage Note and not violative of current law, the Master Servicer shall establish and maintain one or more accounts (each, an "Escrow Account") and deposit and retain therein all collections from the Mortgagors (or advances by the Master Servicer) for the payment of taxes, assessments, hazard insurance premiums or comparable items for the account of the Mortgagors. Nothing herein shall require the Master Servicer to compel a Mortgagor to establish an Escrow Account in violation of applicable law. (b) Withdrawals of amounts so collected from the Escrow Accounts may be made only to effect timely payment of taxes, assessments, hazard insurance premiums, condominium or PUD association dues, or comparable items, to reimburse the Master Servicer out of related collections for any payments made pursuant to Sections 3.01 hereof (with respect to taxes and assessments and insurance premiums) and 3.09 hereof (with respect to hazard insurance), to refund to any Mortgagors any sums determined to be overages, to pay interest, if required by law or the terms of the related Mortgage or Mortgage Note, to Mortgagors on balances in the Escrow Account or to clear and terminate the Escrow Account at the termination of this Agreement in accordance with Section 9.01 hereof. The Escrow Accounts shall not be a part of the Trust Fund. (c) The Master Servicer shall advance any payments referred to in Section 3.06(a) that are not timely paid by the Mortgagors on the date when the tax, premium or other cost for which such payment is intended is due, but the Master Servicer shall be required so to advance only to the extent that such advances, in the good faith judgment of the Master Servicer, will be recoverable by the Master Servicer out of Insurance Proceeds, Liquidation Proceeds or otherwise.