Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Landlord’s Work means the work of constructing the Tenant Improvements.
Tenant Improvements Defined in Exhibit B, if any.
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and
Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.
Base Building Work means the base building work for the Building as described in this Manual.
Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);
Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.
Construction Work means any work in connection with⎯
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.
Subleased Premises means such portions of the Leased Premises being particularly identified on Schedule B, which the parties agree, for the purposes of this Sublease and any square footage calculations pursuant hereto, is approximately 42,244 square feet of office (21,068 square feet on the third floor and 21,176 square feet on the seventh floor) and approximately 9.4312% of common space (building rentable area is 447,917 square feet).
Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;
Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).
Expansion Project has the meaning set forth in Section IV.3.a of this Agreement.
Installation Work means the construction and installation of the System and the Start-up, testing and acceptance (but not the operation and maintenance) thereof; all performed by or for the Power Producer at the Premises.
demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;
On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.
Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.
Customer Premises Equipment or "CPE" means equipment employed on the premises of a Person other than a Carrier to originate, route or terminate Telecommunications (e.g., a telephone, PBX, modem pool, etc.).
School premises means either of the following:
Work area means a room or defined space in a workplace where hazardous chemicals are produced or used, and where employees are present.
Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;