Prices for Work Sample Clauses

Prices for Work. The City shall pay and the Contractor shall receive the prices stipulated in the BID made a part hereof as full compensation for everything performed and furnished and for all risks and obligations undertaken by the Contractor under and as required by the Contract.
Sample 1Sample 2Sample 3
AutoNDA by SimpleDocs
Prices for Work. A. The Owner shall pay and the Contractor shall receive the prices stipulated in the BID made a part hereof as full compensation for everything performed and furnished and for all risks and obligations undertaken by the Contractor under and as required by the Contract.
Sample 1Sample 2
Prices for Work. All work and Services provided hereunder will be provided on a cost reimbursable basis, including reasonable overhead costs. Operator shall use commercially reasonable efforts to keep third party costs incurred to reasonable levels, consistent with market prices. Costs payable to Operator and its affiliates shall not, in the aggregate, exceed costs for similar goods or services that would normally be charged by unrelated third parties and shall in no event exceed the prices that Operator charges to unrelated third parties for such goods or services. The Services provided by Operator hereunder are for routine operation and maintenance activities. Major Maintenance activities are covered by a separate agreement between Company and Operator and are not subject to this Agreement. If Company desires to make Capital Expenditures, Company and Operator must separately agree on the services to be provided and the charges therefor.
Sample 1
Prices for Work. The OWNER shall pay, and the CONTRACTOR shall receive, the prices stipulated in the Bid Schedule attached hereto as full compensation for everything furnished and done by the CONTRACTOR under this Contract, including all work required but not specifically mentioned, and also for all loss or damage arising out of the nature of the work aforesaid, from the action of the elements, or from any unforeseen obstruction or difficulty encountered in the prosecution of the work, for all risks of every disruption connected with the work, for all expense incurred by or in consequence of the suspension or discontinuance of the work as herein specified, and for well and faithfully completing the work and the whole thereof, as herein provided, except that attorney fees in the event of a dispute are expressly excluded from the foregoing.
Sample 1
Prices for Work. A. The Owner shall pay and the Contractor shall receive the prices stipulated in the BID made a part hereof as full compensation for everything performed and furnished and for all risks and obligations undertaken by the Contractor under and as required by the Contract. Pricing for Hot Mix Asphalt shall be adjusted monthly in accordance with MassDOT Document 00811, Special Provisions, Monthly Price Adjustment for Hot Mix Asphalt Mixtures, Revised 2/02/2009 and included as an attachment to this Agreement.
Sample 1

Related to Prices for Work

  • Unit Price Work Work to be paid for on the basis of unit prices as defined and described in the Contract Documents. A percentage markup for overhead or profit shall be included in all unit prices.

  • Quality of Work Consultant agrees that all Services performed under this Agreement will conform to the specifications of the College, be free from errors, and be of professional quality according to applicable industry standards. Upon notice by the College, Consultant will promptly correct any defects without charge to the College unless the request is considered new work by both parties.

  • REPORTING FOR WORK 11.01 An employee reporting for work at the scheduled starting time, unless notified the previous day not to report, and for whom no work is available, shall receive four

  • Fitness for Work 6.2.1 The parties to this Agreement agree that the maintenance of a safe and healthy working environment will be enhanced by adopting a pro-active approach to addressing fitness for work issues, including the misuse of drugs and alcohol in the workplace, workplace stress and fatigue. The management of these occupational health and safety issues will assist to eliminate a contributing factor to workplace injuries and accidents.

  • Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.

  • Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. The Architect, upon a finding of defect or failure to conform, shall immediately notify the State and Contractor, in writing, of the defect. The Contractor shall begin correcting the defective or non-conforming Work within ten (10) days unless the State agrees to a Change Order which reflects the reduction in Contract Sum due to the value of diminishment of the defective or nonconforming Work.

Time is Money Join Law Insider Premium to draft better contracts faster.