Delayed Completion. 7.1 If completion does not take place on the Completion Date in accordance with this contract due to any reason except the Seller’s default, the Buyer shall pay to the Seller on actual completion the sum of £150.00 in respect of the reasonable costs of the Seller’s Conveyancer of preparing and serving any notice to complete lawfully served under Condition 6.8 together with any VAT properly chargeable on those costs
Delayed Completion. If the Date of Substantial Completion is after the Target Occupancy Date (as may be extended as provided in Section 2.01(n)) then Tenant shall be entitled, as its sole and exclusive remedies (i) one
Delayed Completion. 23.1. If, through no fault of Contractor, final completion of the Work is significantly delayed and if Project Manager so confirms, the City shall, upon receipt of Contractor's final Application for Payment and recommendation of Project Manager, and without terminating the Agreement, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by the City for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by Contractor to Project Manager with the Application for such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
Delayed Completion. If the Additional Premises is not Substantially Completed on or before the Scheduled Additional Premises Commencement Date; then, except as otherwise provided in Section 6 of this Amendment with respect to delays in Substantial Completion of the Additional Premises caused by Tenant Delays, (a) as Tenant's sole and exclusive remedy, the obligation of Tenant to pay Rent shall not commence until the date the Additional Premises is Substantially Completed (or such earlier date as Tenant occupies the Additional Premises); and (b) Landlord shall not be liable to Tenant for any loss, cost or damage arising from such delay.
Delayed Completion. 11.1 The Parties acknowledge that not all of the Business Assets may be capable of being transferred to the JV Companies at Completion.
Delayed Completion. (a) Landlord shall diligently attempt to cause Landlord’s Work to be Substantially Completed on or before the Target Completion Date. Notwithstanding anything to the contrary, if, but only to the extent that, any Tenant’s Delay causes a delay in the Landlord’s Work, then Target Completion Date and the Substantial Completion Date shall be deemed to be the dates when the Target Completion Dates and the Substantial Completion Dates, as the case may be, would have occurred but for such Tenant’s Delay. Any delay claimed by Landlord shall be substantiated in writing and accompanied by a statement as to the number of days of Tenant’s Delay, which notice of delay shall be delivered within five (5) Business Days after the extent of the Tenant’s Delay is reasonably ascertainable. If Landlord and Tenant dispute the existence of a Tenant’s Delay or the number of days resulting from a Tenant’s Delay, such dispute shall be resolved by the Arbitrator.
Delayed Completion. These provisions in the Development Agreement will mirror the D & B Contract and any liquidated damages payable to the Council and/or the Academy Company must be a genuine reflection of any losses likely to be incurred by them in the event of any delay in the completion of the building works and corresponding delay in the Academy Company being able to take up occupation of the new Academy building 3.7. Novation The D & B Contract will be novated to the Academy Company immediately following the expiry of the defects liability period under the Contract. Thereafter, the Academy Company will have a direct contractual relationship with the Building Contractor and the Council will have no further obligations in relation to the D & B Contract or the enforcement of any rights thereunder
Delayed Completion. Except as provided elsewhere in this Agreement, A-E’s compensation shall be paid at the time and in the amount noted, notwithstanding a delay in completion of the Project or the reduction in the final construction cost by reason of penalties, liquidated damages, or other amounts withheld from Contractor.
Delayed Completion. Any proceeds of the Term Advances drawn at Completion to be applied in discharging the purchase price for any Delayed Completion shall be paid to the credit of a Cash Collateral Account in the name of UK Xxxxx until so applied. In the event that such proceeds are not applied in discharging the purchase price for such Delayed Completion in accordance with the terms of the Acquisition Agreement, the relevant Borrower shall apply such proceeds in prepayment of the Facilities in accordance with Clause 8.5 (Prepayments: Order of Application).
Delayed Completion. If completion of the sale and purchase of the Property is delayed beyond 2.30 pm on the Completion Date due to the act or default of the Buyer then, without prejudice to any other rights of the Seller:
